81 FR 22603 - Submission for OMB Review; Accident Prevention Plans and Recordkeeping

DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION

Federal Register Volume 81, Issue 74 (April 18, 2016)

Page Range		22603-22604
FR Document		2016-08870

Under the provisions of the Paperwork Reduction Act, Regulatory Secretariat Division will be submitting to the Office of Management and Budget (OMB) a request to review and approve an extension of a previously approved information collection requirement concerning Accident Prevention Plans and Recordkeeping. A notice published in the Federal Register at 81 FR 6517 on February 8, 2016. No comments were received.

Federal Register, Volume 81 Issue 74 (Monday, April 18, 2016)

[Federal Register Volume 81, Number 74 (Monday, April 18, 2016)]
[Notices]
[Pages 22603-22604]
From the Federal Register Online  [www.thefederalregister.org]
[FR Doc No: 2016-08870]


-----------------------------------------------------------------------

DEPARTMENT OF DEFENSE

GENERAL SERVICES ADMINISTRATION

NATIONAL AERONAUTICS AND SPACE ADMINISTRATION

[OMB Control No. 9000-0060; Docket 2016-0053; Sequence 5]


Submission for OMB Review; Accident Prevention Plans and 
Recordkeeping

AGENCY: Department of Defense (DOD), General Services Administration 
(GSA), and National Aeronautics and Space Administration (NASA).

ACTION: Notice of request for an extension of an information collection 
requirement regarding an existing OMB clearance.

-----------------------------------------------------------------------

SUMMARY: Under the provisions of the Paperwork Reduction Act, 
Regulatory Secretariat Division will be submitting to the Office of 
Management and Budget (OMB) a request to review and approve an 
extension of a previously approved information collection requirement 
concerning Accident Prevention Plans and Recordkeeping. A notice 
published in the Federal Register at 81 FR 6517 on February 8, 2016. No 
comments were received.

DATES: Submit comments on or before May 18, 2016.

ADDRESSES: Submit comments regarding this burden estimate or any other 
aspect of this collection of information, including suggestions for 
reducing this burden to: Office of Information and Regulatory Affairs 
of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, 
DC 20503. Additionally submit a copy to GSA by any of the following 
methods:
     Regulations.gov: http://www.regulations.gov. Submit 
comments via the Federal eRulemaking portal by searching for 
Information Collection 9000-0060, Accident Prevention Plans and 
Recordkeeping. Select the link ``Comment Now'' that corresponds with 
``Information Collection 9000-0060, Accident Prevention Plans and 
Recordkeeping''. Follow the instructions provided on the screen. Please 
include your name, company name (if any), and ``Information Collection 
9000-0060, Accident Prevention Plans and Recordkeeping'' on your 
attached document.
     Mail: General Services Administration, Regulatory 
Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. 
ATTN: Ms. Flowers/IC 9000-0060, Accident Prevention Plans and 
Recordkeeping.

[[Page 22604]]

    Instructions: Please submit comments only and cite Information 
Collection 9000-0060, Accident Prevention Plans and Recordkeeping, in 
all correspondence related to this collection. Comments received 
generally will be posted without change to http://www.regulations.gov, 
including any personal and/or business confidential information 
provided. To confirm receipt of your comment(s), please check 
www.regulations.gov, approximately two to three days after submission 
to verify posting (except allow 30 days for posting of comments 
submitted by mail).

FOR FURTHER INFORMATION CONTACT: Mr. Curtis E. Glover, Sr., Procurement 
Analyst, Contract Policy Division, GSA, telephone 202-501-1448 or email 
at [email protected].

SUPPLEMENTARY INFORMATION:

A. Purpose

    The FAR clause at 52.236-13, Accident Prevention, requires Federal 
construction contractors to keep records of accidents incident to work 
performed under the contract that result in death, traumatic injury, 
occupational disease or damage to property, materials, supplies or 
equipment. Records of personal inquiries are required by the Department 
of Labor's (DOL) Occupational Safety and Health Administration 
regulations (OSHA). The records maintained by the contractor are used 
to evaluate compliance and may be used in workmen's compensation cases. 
The Federal Acquisition Regulation (FAR) requires records of damage to 
property, materials, supplies or equipment to provide background 
information when claims are brought against the Government.
    If the contract involves work of a long duration, or hazardous 
nature, the contracting officer shall insert the clause with its 
alternate that requires the contractor to submit a written proposed 
plan for implementing the clause. The plan shall include an analysis of 
the significant hazards to life, limb, and property inherent in 
performing the contract and a plan for controlling the hazards. The 
Accident Prevention Plan (APP) is analyzed by the contracting officer 
along with the agency safety representatives to determine if the 
proposed plan will meet the requirements of safety regulations and 
applicable statutes.

B. Annual Reporting Burden

    Respondents: 215.
    Responses per Respondent: 1.
    Annual Responses: 215.
    Hours per Response: 22.
    Total Burden Hours: 4,730

C. Public Comments

    Public comments are particularly invited on: Whether this 
collection of information is necessary; whether it will have practical 
utility; whether our estimate of the public burden of this collection 
of information is accurate, and based on valid assumptions and 
methodology; ways to enhance the quality, utility, and clarity of the 
information to be collected; and ways in which we can minimize the 
burden of the collection of information on those who are to respond, 
through the use of appropriate technological collection techniques or 
other forms of information technology.
    Obtaining Copies of Proposals: Requesters may obtain a copy of the 
information collection documents from the General Services 
Administration, Regulatory Secretariat Division (MVCB), 1800 F Street 
NW., Washington, DC 20405, telephone 202-501-4755. Please cite OMB 
Control No. 9000-0060, Accident Prevention Plans and Recordkeeping, in 
all correspondence.

    Dated: April 13, 2016.
Lorin S. Curit,
Director, Federal Acquisition Policy Division, Office of Governmentwide 
Acquisition Policy, Office of Acquisition Policy, Office of 
Governmentwide Policy.
[FR Doc. 2016-08870 Filed 4-15-16; 8:45 am]
 BILLING CODE 6820-EP-P

Federal Register / Vol. 81, No. 74 / Monday, April 18, 2016 / Notices 22603

of this collection of information, that establishes the terms and DEPARTMENT OF DEFENSE
including suggestions for reducing this conditions of employment for a specific
burden to: Office of Information and construction project. FAR 22.503(b) GENERAL SERVICES
Regulatory Affairs of OMB, Attention: provides that an agency may, if ADMINISTRATION
Desk Officer for GSA, Room 10236, appropriate, require that every
NEOB, Washington, DC 20503. contractor and subcontractor engaged in NATIONAL AERONAUTICS AND
Additionally submit a copy to GSA by construction on the project agree, for SPACE ADMINISTRATION
any of the following methods: that project, to negotiate or become a [OMB Control No. 9000–0060; Docket 2016–
• Regulations.gov: http:// party to a project labor agreement with 0053; Sequence 5]
www.regulations.gov. Submit comments one or more labor organizations if the
via the Federal eRulemaking portal by agency decides that the use of project Submission for OMB Review; Accident
searching the OMB control number. labor agreements will— Prevention Plans and Recordkeeping
Select the link ‘‘Submit a Comment’’ (1) Advance the Federal Government’s
that corresponds with ‘‘Information interest in achieving economy and AGENCY: Department of Defense (DOD),
Collection 9000–0175, Use of Project efficiency in Federal procurement, General Services Administration (GSA),
Labor Agreements for Federal producing labor-management stability, and National Aeronautics and Space
Construction Projects’’. Follow the and ensuring compliance with laws and Administration (NASA).
instructions provided at the ‘‘Submit a regulations governing safety and health, ACTION: Notice of request for an
Comment’’ screen. Please include your equal employment opportunity, labor extension of an information collection
name, company name (if any), and and employment standards, and other requirement regarding an existing OMB
‘‘Information Collection 9000–0175, Use matters; and, clearance.
of Project Labor Agreements for Federal (2) Be consistent with law.
Construction Projects’’ on your attached SUMMARY: Under the provisions of the
document. B. Annual Reporting Burden Paperwork Reduction Act, Regulatory
• Mail: General Services Secretariat Division will be submitting
Respondents: 70. to the Office of Management and Budget
Administration, Regulatory Secretariat Responses per Respondent: 1.
Division (MVCB), 1800 F Street NW., (OMB) a request to review and approve
Annual Responses: 70. an extension of a previously approved
Washington, DC 20405. ATTN: Ms.
Flowers/IC 9000–0175, Use of Project Hours per Response: 1. information collection requirement
Labor Agreements for Federal Total Burden Hours: 70. concerning Accident Prevention Plans
Construction Projects. and Recordkeeping. A notice published
C. Public Comments in the Federal Register at 81 FR 6517 on
Instructions: Please submit comments
only and cite Information Collection Public comments are particularly February 8, 2016. No comments were
9000–0175, Use of Project Labor invited on: Whether this collection of received.
Agreements for Federal Construction information is necessary for the proper DATES: Submit comments on or before
Projects, in all correspondence related performance of functions of the FAR, May 18, 2016.
to this collection. Comments received and whether it will have practical
ADDRESSES: Submit comments regarding
generally will be posted without change utility; whether our estimate of the
this burden estimate or any other aspect
to http://www.regulations.gov, including public burden of this collection of
of this collection of information,
any personal and/or business information is accurate, and based on
including suggestions for reducing this
confidential information provided. To valid assumptions and methodology;
burden to: Office of Information and
confirm receipt of your comment(s), ways to enhance the quality, utility, and
Regulatory Affairs of OMB, Attention:
please check www.regulations.gov, clarity of the information to be
Desk Officer for GSA, Room 10236,
approximately two to three days after collected; and ways in which we can
NEOB, Washington, DC 20503.
submission to verify posting (except minimize the burden of the collection of
Additionally submit a copy to GSA by
allow 30 days for posting of comments information on those who are to
any of the following methods:
submitted by mail). respond, through the use of appropriate
• Regulations.gov: http://
FOR FURTHER INFORMATION CONTACT: Mr.
technological collection techniques or
www.regulations.gov. Submit comments
Edward Loeb, Procurement Analyst, other forms of information technology.
via the Federal eRulemaking portal by
Office of Governmentwide Acquisition Obtaining Copies of Proposals: searching for Information Collection
Policy, at telephone 202–501–0650 or Requesters may obtain a copy of the 9000–0060, Accident Prevention Plans
via email to edward.loeb@gsa.gov. information collection documents from and Recordkeeping. Select the link
the General Services Administration, ‘‘Comment Now’’ that corresponds with
SUPPLEMENTARY INFORMATION:
Regulatory Secretariat Division (MVCB), ‘‘Information Collection 9000–0060,
A. Purpose 1800 F Street NW., Washington, DC Accident Prevention Plans and
FAR 22.501 prescribes policies and 20405, telephone 202–501–4755. Please Recordkeeping’’. Follow the instructions
procedures to implement Executive cite OMB Control No. 9000–0175, Use of provided on the screen. Please include
Order 13502, February 6, 2009 which Project Labor Agreements for Federal your name, company name (if any), and
encourages Federal agencies to consider Construction Projects, in all ‘‘Information Collection 9000–0060,
the use of a project labor agreement correspondence. Accident Prevention Plans and
mstockstill on DSK4VPTVN1PROD with NOTICES

(PLA), as they may decide appropriate, Dated: April 13, 2016. Recordkeeping’’ on your attached
on large-scale construction projects, Lorin S. Curit, document.
where the total cost to the Government Director, Federal Acquisition Policy Division, • Mail: General Services
is more than $25 million, in order to Office of Governmentwide Acquisition Policy, Administration, Regulatory Secretariat
promote economy and efficiency in Office of Acquisition Policy, Office of Division (MVCB), 1800 F Street NW.,
Federal procurement. A PLA is a pre- Governmentwide Policy. Washington, DC 20405. ATTN: Ms.
hire collective bargaining agreement [FR Doc. 2016–08873 Filed 4–15–16; 8:45 am] Flowers/IC 9000–0060, Accident
with one or more labor organizations BILLING CODE 6820–EP–P Prevention Plans and Recordkeeping.

VerDate Sep<11>2014 17:54 Apr 15, 2016 Jkt 238001 PO 00000 Frm 00037 Fmt 4703 Sfmt 4703 E:\FR\FM\18APN1.SGM 18APN1

22604 Federal Register / Vol. 81, No. 74 / Monday, April 18, 2016 / Notices

Instructions: Please submit comments Total Burden Hours: 4,730 database. A notice was published in the
only and cite Information Collection Federal Register at 81 FR 6515 on
C. Public Comments
9000–0060, Accident Prevention Plans February 8, 2016. No comments were
and Recordkeeping, in all Public comments are particularly received.
correspondence related to this invited on: Whether this collection of
DATES: Submit comments on or before
collection. Comments received generally information is necessary; whether it will
May 18, 2016.
will be posted without change to have practical utility; whether our
ADDRESSES: Submit comments regarding
http://www.regulations.gov, including estimate of the public burden of this
collection of information is accurate, this burden estimate or any other aspect
any personal and/or business of this collection of information,
confidential information provided. To and based on valid assumptions and
methodology; ways to enhance the including suggestions for reducing this
confirm receipt of your comment(s), burden to: Office of Information and
please check www.regulations.gov, quality, utility, and clarity of the
information to be collected; and ways in Regulatory Affairs of OMB, Attention:
approximately two to three days after Desk Officer for GSA, Room 10236,
submission to verify posting (except which we can minimize the burden of
the collection of information on those NEOB, Washington, DC 20503.
allow 30 days for posting of comments Additionally submit a copy to GSA by
submitted by mail). who are to respond, through the use of
appropriate technological collection any of the following methods:
FOR FURTHER INFORMATION CONTACT: Mr. • Regulations.gov: http://
Curtis E. Glover, Sr., Procurement techniques or other forms of information
www.regulations.gov. Submit comments
Analyst, Contract Policy Division, GSA, technology.
Obtaining Copies of Proposals: via the Federal eRulemaking portal by
telephone 202–501–1448 or email at searching for the OMB control number.
Requesters may obtain a copy of the
curtis.glover@gsa.gov. Select the link ‘‘Submit a Comment’’
information collection documents from
SUPPLEMENTARY INFORMATION: the General Services Administration, that corresponds with ‘‘Information
Regulatory Secretariat Division (MVCB), Collection 9000–0159, Central
A. Purpose Contractor Registration.’’ Follow the
1800 F Street NW., Washington, DC
The FAR clause at 52.236–13, 20405, telephone 202–501–4755. Please instructions provided at the ‘‘Submit a
Accident Prevention, requires Federal cite OMB Control No. 9000–0060, Comment’’ screen. Please include your
construction contractors to keep records Accident Prevention Plans and name, company name (if any), and
of accidents incident to work performed Recordkeeping, in all correspondence. ‘‘Information Collection 9000–0159,
under the contract that result in death, Central Contractor Registration’’ on your
traumatic injury, occupational disease Dated: April 13, 2016. attached document.
or damage to property, materials, Lorin S. Curit, • Mail: General Services
supplies or equipment. Records of Director, Federal Acquisition Policy Division, Administration, Regulatory Secretariat
personal inquiries are required by the Office of Governmentwide Acquisition Policy, Division (MVCB), 1800 F Street NW.,
Department of Labor’s (DOL) Office of Acquisition Policy, Office of Washington, DC 20405. ATTN: Ms.
Occupational Safety and Health Governmentwide Policy. Flowers/IC 9000–0159, Central
Administration regulations (OSHA). The [FR Doc. 2016–08870 Filed 4–15–16; 8:45 am] Contractor Registration.
records maintained by the contractor are BILLING CODE 6820–EP–P Instructions: Please submit comments
used to evaluate compliance and may be only and cite Information Collection
used in workmen’s compensation cases. 9000–0159, Central Contractor
The Federal Acquisition Regulation DEPARTMENT OF DEFENSE Registration, in all correspondence
(FAR) requires records of damage to related to this collection. Comments
GENERAL SERVICES received generally will be posted
property, materials, supplies or
ADMINISTRATION without change to http://
equipment to provide background
information when claims are brought www.regulations.gov, including any
NATIONAL AERONAUTICS AND personal and/or business confidential
against the Government.
SPACE ADMINISTRATION information provided. To confirm
If the contract involves work of a long
duration, or hazardous nature, the [OMB Control No. 9000–0159; Docket 2016– receipt of your comment(s), please
contracting officer shall insert the clause 0053; Sequence 4] check www.regulations.gov,
with its alternate that requires the approximately two to three days after
contractor to submit a written proposed Submission for OMB Review; Central submission to verify posting (except
plan for implementing the clause. The Contractor Registration allow 30 days for posting of comments
plan shall include an analysis of the AGENCY: Department of Defense (DOD), submitted by mail).
significant hazards to life, limb, and General Services Administration (GSA), FOR FURTHER INFORMATION CONTACT: Mr.
property inherent in performing the and National Aeronautics and Space Curtis E. Glover, Sr., Procurement
contract and a plan for controlling the Administration (NASA). Analyst, Office of Governmentwide
hazards. The Accident Prevention Plan ACTION: Notice of request for public Policy, GSA, 202–501–1448, or via
(APP) is analyzed by the contracting comments regarding an extension to an email at curtis.glover@gsa.gov.
officer along with the agency safety existing OMB clearance. SUPPLEMENTARY INFORMATION:
representatives to determine if the
proposed plan will meet the SUMMARY: Under the provisions of the A. Purpose
mstockstill on DSK4VPTVN1PROD with NOTICES

requirements of safety regulations and Paperwork Reduction Act, the The Federal Acquisition Regulation
applicable statutes. Regulatory Secretariat Division will be (FAR) Subpart 4.11 prescribes policies
submitting to the Office of Management and procedures for requiring contractor
B. Annual Reporting Burden and Budget (OMB) a request to review registration in the Central Contractor
Respondents: 215. and approve an extension of a Registration (CCR) database. The CCR is
Responses per Respondent: 1. previously approved information the primary vendor database for the U.S.
Annual Responses: 215. collection requirement concerning the Federal Government. CCR collects,
Hours per Response: 22. Central Contractor Registration validates, stores, and disseminates data

VerDate Sep<11>2014 17:54 Apr 15, 2016 Jkt 238001 PO 00000 Frm 00038 Fmt 4703 Sfmt 4703 E:\FR\FM\18APN1.SGM 18APN1

Document Created: 2016-04-16 01:46:06
Document Modified: 2016-04-16 01:46:06

Category		Regulatory Information
Collection		Federal Register
sudoc Class		AE 2.7: GS 4.107: AE 2.106:
Publisher		Office of the Federal Register, National Archives and Records Administration
Section		Notices
Action		Notice of request for an extension of an information collection requirement regarding an existing OMB clearance.
Dates		Submit comments on or before May 18, 2016.
Contact		Mr. Curtis E. Glover, Sr., Procurement Analyst, Contract Policy Division, GSA, telephone 202-501-1448 or email at [email protected]
FR Citation		81 FR 22603

81 FR 22603 - Submission for OMB Review; Accident Prevention Plans and Recordkeeping

DEPARTMENT OF DEFENSEGENERAL SERVICES ADMINISTRATIONNATIONAL AERONAUTICS AND SPACE ADMINISTRATION

Federal Register Volume 81, Issue 74 (April 18, 2016)

DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION