83_FR_12980 83 FR 12922 - Revise and Streamline VA Acquisition Regulation-Parts 811 and 832

83 FR 12922 - Revise and Streamline VA Acquisition Regulation-Parts 811 and 832

DEPARTMENT OF VETERANS AFFAIRS

Federal Register Volume 83, Issue 58 (March 26, 2018)

Page Range12922-12933
FR Document2018-04002

The Department of Veterans Affairs (VA) is proposing to amend and update its VA Acquisition Regulation (VAAR) in phased increments to revise or remove any policy superseded by changes in the Federal Acquisition Regulation (FAR), to remove any procedural guidance internal to VA into the VA Acquisition Manual (VAAM), and to incorporate any new agency specific regulations or policies. These changes seek to streamline and align the VAAR with the FAR and remove outdated and duplicative requirements and reduce burden on contractors. The VAAM incorporates portions of the removed VAAR as well as other internal agency acquisition policy. VA will rewrite certain parts of the VAAR and VAAM, and as VAAR parts are rewritten, we'll publish them in the Federal Register. VA will combine related topics, as appropriate. In particular, this rulemaking revises VAAR Parts 811-- Describing Agency Needs and Part 832--Contract Financing, as well as affected parts 801--Department of Veterans Affairs Acquisition Regulation System, 852--Solicitation Provisions and Contract Clauses, and 870--Special Procurement Controls.

Federal Register, Volume 83 Issue 58 (Monday, March 26, 2018)
[Federal Register Volume 83, Number 58 (Monday, March 26, 2018)]
[Proposed Rules]
[Pages 12922-12933]
From the Federal Register Online  [www.thefederalregister.org]
[FR Doc No: 2018-04002]


=======================================================================
-----------------------------------------------------------------------

DEPARTMENT OF VETERANS AFFAIRS

[8320-01]

48 CFR Parts 801, 811, 832, 852, and 870

RIN 2900-AP81


Revise and Streamline VA Acquisition Regulation--Parts 811 and 
832

AGENCY: Department of Veterans Affairs.

ACTION: Proposed rule.

-----------------------------------------------------------------------

SUMMARY: The Department of Veterans Affairs (VA) is proposing to amend 
and update its VA Acquisition Regulation (VAAR) in phased increments to 
revise or remove any policy superseded by changes in the Federal 
Acquisition Regulation (FAR), to remove any procedural guidance 
internal to VA into the VA Acquisition Manual (VAAM), and to 
incorporate any new agency specific regulations or policies. These 
changes seek to streamline and align the VAAR with the FAR and remove 
outdated and duplicative requirements and reduce burden on contractors. 
The VAAM incorporates portions of the removed VAAR as well as other 
internal agency acquisition policy. VA will rewrite certain parts of 
the VAAR and VAAM, and as VAAR parts are rewritten, we'll publish them 
in the Federal Register. VA will combine related topics, as 
appropriate. In particular, this rulemaking revises VAAR Parts 811--
Describing Agency Needs and Part 832--Contract Financing, as well as 
affected parts 801--Department of Veterans Affairs Acquisition 
Regulation System, 852--Solicitation Provisions and Contract Clauses, 
and 870--Special Procurement Controls.

DATES: Comments must be received on or before May 25, 2018 to be 
considered in the formulation of the final rule.

ADDRESSES: Written comments may be submitted through 
www.Regulations.gov; by mail or hand-delivery to Director, Regulation 
Policy and Management (00REG), Department of Veterans Affairs, 810 
Vermont Avenue NW, Room 1063B, Washington, DC 20420; or by fax to (202) 
273-9026. Comments should indicate that they are submitted in response 
to ``RIN 2900-AP81--Revise and Streamline VA Acquisition Regulation to 
Adhere to Federal Acquisition Regulation Principles (VAAR Case 2014-
V004--parts 811, 832).'' Copies of comments received will be available 
for public inspection in the Office of Regulation Policy and 
Management, Room 1063B, between the hours of 8:00 a.m. and 4:30 p.m., 
Monday through Friday (except holidays). Please call (202) 461-4902 for 
an appointment. (This is not a toll-free number.) In addition, during 
the comment period, comments may be viewed online through the Federal 
Docket Management System (FDMS) at www.Regulations.gov.

FOR FURTHER INFORMATION CONTACT: Mr. Ricky Clark, Senior Procurement 
Analyst, Procurement Policy and Warrant Management Services, 003A2A, 
425 I Street NW, Washington DC 20001, (202) 697-3565. (This is not a 
toll-free telephone number.)

SUPPLEMENTARY INFORMATION:

Background

    This rulemaking is issued under the authority of the Office of 
Federal Procurement Policy (OFPP) Act which provides the authority for 
an agency head to issue agency acquisition regulations that implement 
or supplement the FAR.
    VA is proposing to revise the VAAR to add new policy or regulatory 
requirements and to remove any redundant guidance and guidance that is 
applicable only to VA's internal operating processes or procedures. 
Codified acquisition regulations may be amended and revised only 
through rulemaking. All amendments, revisions, and removals have been 
reviewed and concurred with by VA's Integrated Product Team of agency 
stakeholders.
    The VAAR uses the regulatory structure and arrangement of the FAR 
and headings and subject areas are broken up consistent with the FAR 
content. The VAAR is divided into subchapters, parts (each of which 
covers a separate aspect of acquisition), subparts, sections, and 
subsections.
    The Office of Federal Procurement Policy Act, as codified in 41 
U.S.C. 1707, provides the authority for the Federal Acquisition 
Regulation and for the issuance of agency acquisition regulations 
consistent with the FAR.
    When Federal agencies acquire supplies and services using 
appropriated funds, the purchase is governed by the FAR, set forth at 
Title 48 Code of Federal Regulations (CFR), chapter 1, parts 1 through 
53, and the agency regulations that implement and supplement the FAR. 
The VAAR is set forth at Title 48 CFR, chapter 8, parts 801 to 873.

[[Page 12923]]

Discussion and Analysis

    The VA proposes to make the following changes to the VAAR in this 
phase of its revision and streamlining initiative. For procedural 
guidance cited below that is proposed to be deleted from the VAAR, each 
section cited for removal has been considered for inclusion in VA's 
internal agency operating procedures in accordance with FAR 
1.301(a)(2). Similarly, delegations of authority that are removed from 
the VAAR will be included in the VA Acquisition Manual (VAAM) as 
internal agency guidance.

VAAR Part 801--Department of Veterans Affairs Acquisition Regulation 
System

    We propose to amend the authority for part 801 to remove the 
citation of 38 U.S.C. 501, and to add 41 U.S.C. 1121, 41 U.S.C. 1303, 
an updated positive law codification of, to reflect additional 
authority of the VA as an executive agency to issue regulations that 
are essential to implement Governmentwide policies and procedures in 
the agency, as well as to issue additional policies and procedures 
required to satisfy the specific needs of the VA; and 41 U.S.C. 1702, 
which addresses overall direction of procurement policy, acquisition 
planning and management responsibilities of VA's Chief Acquisition 
Officer.
    This proposed rule contains existing information collection 
requirements. The proposed rule would result in multiple actions 
affecting these information collections, including outright removal of 
the information collection and redesignating the information collection 
burden associated with several clauses or provisions by renumbering the 
clause or provision. We propose to revise certain clause or provision 
numbers in VAAR part 801 only when removing the actual information 
collection and its associated burden, or when redesignating and 
renumbering the clause or provision under the associated Office of 
Management and Budget (OMB) approval number.
    In section 801.106, OMB approval under the Paperwork Reduction Act, 
we propose to amend section 801.106 table columns titled ``48 CFR part 
or section where identified and described,'' and ``Current OMB control 
number.'' We propose to remove the reference to section 832.006-4 and 
the associated OMB control number 2900-0688. This information 
collection burden under the associated OMB control number was 
previously removed via a published Notice of Office of Management and 
Budget Action dated March 2, 2015, Information Collection Reference 
(ICR) 201406-2900-017, which approved the removal of the information 
collection and a reduction of the associated burden under OMB approval 
number 2900-0688. Therefore, it is proposed for removal from this 
table. Information collection is approved at the FAR level under FAR 
OMB approval number 9000-0138, making it unnecessary for a separate 
information collection approval in the VAAR.
    In section 801.106, OMB approval under the Paperwork Reduction Act, 
we propose to amend section 801.106 table columns titled ``48 CFR part 
or section where identified and described,'' and ``Current OMB control 
number.'' We propose to remove the reference to subsection 852.211-71, 
Special Notice, and discontinue the corresponding OMB control number 
2900-0588, as the provision conflicts with FAR 52.214-21. It currently 
requires literature to be provided after award and thus conflicts with 
the FAR and the Government's procedures for evaluating relevant 
materials during source selection and prior to award decisions.
    In section 801.106, in reference to the table described, we propose 
to remove the reference to subsection 852.211-73, Brand Name or Equal, 
and discontinue the corresponding OMB control number 2900-0585, as the 
topical area the clause covers, ``brand name or equal,'' or ``items 
peculiar to one manufacturer,'' has sufficient coverage in FAR 11.105 
and the associated provision in FAR 52.211-6, Brand Name or Equal.
    In section 801.106, in reference to the table described, we propose 
to remove the reference to section 852.236-82, Payments under fixed-
price construction contracts (without NAS), and remove the reference to 
section 852.236-83, Payments under fixed-price construction contracts 
(including NAS). Both of these clauses, pertaining to ``payments under 
fixed-price construction,'' have been renumbered to reflect their 
prescription under Part 832. The associated OMB control number 2900-
0422 will now reflect information collections under the new clause 
numbers--852.232-70 and 852.232-71 as described in further detail under 
the Paperwork Reduction Act section of this preamble, although these 
are not new collections.

Subchapter B--Competition and Acquisition Planning

    We propose to revise the title of Subchapter B to conform to the 
title in the Federal Acquisition Regulation, 48 CFR, chapter 1, 
``Acquisition Planning.''

VAAR Part 811--Describing Agency Needs

    We propose to revise the Table of Contents to reflect the revision 
of subparts 811.1 and 811.2, and the deletion of subparts 811.4, 811.5, 
and 811.6.
    We propose to revise the part 811 authorities to add 41 U.S.C. 
1702, which addresses overall direction of procurement policy, 
acquisition planning and management responsibilities of VA's Chief 
Acquisition Officer, and 41 U.S.C. 1303, an updated positive law 
codification to reflect additional authority of the VA as an executive 
agency to issue regulations that are essential to implement 
Governmentwide policies and procedures in the agency, as well as to 
issue additional policies and procedures required to satisfy the 
specific needs of the VA.
    We propose to remove section 811.001, Definitions, because the 
coverage in FAR 11.104 provides adequate coverage of what brand name or 
equal purchase descriptions must include. The VAAR had merely 
paraphrased the same information. In accordance with FAR drafting 
standards and the requirement in FAR 1.304(b)(1) that agency 
acquisition regulations shall not unnecessarily repeat, paraphrase, or 
otherwise restate material contained in the FAR, this section is 
therefore proposed for removal.
    In subpart 811.1, Selecting and Developing Requirements Documents, 
we propose to remove section 811.103, Market acceptance, and the 
underlying subsection 811.103-70, Technical industry standards. We 
propose to revise the prescription to clause 852.211-72, Technical 
industry standards, for clarity and simplification of the language, and 
to move the prescription of the clause to 811.204-70 to comport with 
the FAR structure, as technical industry standards are not related to 
coverage in FAR 11.103, but would fall under FAR 11.204.
    We propose to remove the section title at 811.104, Use of Brand 
Name or Equal purchase descriptions, and subsection at 811.104-70, 
Brand name or equal purchase descriptions, because FAR 11.104, provides 
adequate coverage of what brand name or equal purchase descriptions 
must include.
    We propose to remove subsections 811.104-71, Purchase description 
clauses, and 811.104-72, Limited application of brand name or equal, 
because the subject is adequately covered in FAR clause 52.211-6, Brand 
name or equal.

[[Page 12924]]

    We propose to remove subsection 811.104-73, Bid samples, as 
coverage is adequate in FAR 14.202-4, and clause 52.214-20.
    We propose to remove subsection 811.104-74, Bid evaluation and 
award, since it duplicates coverage in FAR clause 52.211-6.
    We propose to remove subsection 811.104-75, Procedure for 
negotiated procurements, since there is no need to have separate policy 
and procedures for negotiated and sealed bid solicitations. FAR covers 
``brand name or equal'' without a distinction between sealed bid and 
negotiated solicitations.
    We propose to remove 811.105, Items peculiar to one manufacturer, 
since the subject is adequately covered in FAR 11.105.
    In subpart 811.1, section 811.107, Contract clauses, we propose to 
amend the number and title of the existing section to read as 811.107-
70, Contract clause, to better reflect its placement in accordance with 
FAR numbering conventions. It fits intelligibly as a supplement to FAR 
11.107, Solicitation provision, but the VAAR is supplementing with a 
clause in this area and not a provision, necessitating the more 
accurate title. Subsection 811.107-70 prescribes a new clause 852.211-
70, Equipment Operation and Maintenance Manuals, which replaces the 
existing clause 852.211-70, Service data manuals.
    In subpart 811.2, Using and Maintaining Requirements Documents, we 
propose to remove section 811.202, Maintenance of standardization 
documents, as it is procedural in nature and will be moved to the VAAM.
    Under subpart 811.2, we propose to revise and renumber section 
811.204, Contract clause, to subsection 811.204-70, Contract clause, 
which contains text prescribing clause 852.211-72, Technical industry 
standards. The prescription for 852.211-72 was moved from 811.103-70 to 
better comport with FAR structure numbering and arrangement.
    We propose to remove subparts 811.4, Delivery or Performance 
Schedules, and 811.5, Liquidated Damages, as the policy is redundant to 
FAR guidance.
    We propose to remove subpart 811.6, Priorities and Allocations, as 
it provides internal procedural guidance not having a significant 
effect beyond the internal operating procedures of the VA (see FAR 
1.301(b)) and which will be moved to the VAAM.

VAAR Part 832--Contract Financing

    We propose to revise the Table of Contents to reflect the revision 
of subparts 832.1, 832.2, 832.9 and 832.70, and the deletion of 
subparts 832.5, 832.8, and 832.11.
    We propose to revise the part 832 authorities to add 41 U.S.C. 
1702, which addresses overall direction of procurement policy, 
acquisition planning and management responsibilities of VA's Chief 
Acquisition Officer; and 41 U.S.C. 1303, to include an updated positive 
law codification.
    We propose to add section 832.001, Definitions. This section would 
add three definitions of terms relating to electronic invoicing. We 
propose to amend subsection 832.006-1, General, to spell out the title 
of Senior Procurement Executive (SPE) and to delete the last sentence 
as it provides internal procedural guidance not having a significant 
effect beyond the internal operating procedures of the VA (see FAR 
1.301(b)) and which will be moved to the VAAM.
    We propose to remove subsection 832.006-2, Definitions, which only 
included one definition for the Remedy Coordination Official (RCO). 
This information would be added in subsection 832.006-4 and would make 
the need for a separate definition repeating the same thing 
unnecessary.
    We propose to remove subsection 832.006-3, Responsibilities, as it 
provides internal procedural guidance not having a significant effect 
beyond the internal operating procedures of VA (see FAR 1.301(b)) and 
which will be moved to the VAAM.
    We propose to amend subsection 832.006-4, Procedures, to update the 
existing VA agency procedures and to delete paragraphs (a) and (c) as 
internal operating procedures of VA not having a significant effect 
beyond the internal operating procedures of the VA (see FAR 1.301(b)) 
and which will be moved to the VAAM. We propose to add new paragraphs 
(b), (e), and (g) to implement FAR required agency procedures which 
describes notifying contractors, the contractor's right to provide 
information on its behalf concerning a finding of fraud in payment 
requests, the time period to provide the information to the Government 
and that the Senior Procurement Executive (SPE) will provide a copy of 
each final determination and supporting documentation to the 
contractor, the RCO, the Contracting Officer, and the VA Office of 
Inspector General (OIG).
    In subpart 832.1, Non-Commercial Item Purchase Financing, we 
propose to amend section 832.111, Contract clauses for non-commercial 
purchases, to renumber the section as subsection 832.111-70, retitle it 
as ``VA contract clauses for non-commercial purchases,'' and to 
reconfigure the paragraphs to conform more closely to FAR prescription 
language for clauses and provisions. Also, the clauses were renumbered 
to reflect that they are prescribed in part 832 and not 836 as they 
were previously numbered, and the clauses were retitled for 
clarification.
    In subpart 832.2, Commercial Item Purchase Financing, we propose to 
remove section 832.201, Statutory authority, and move internal 
procedural guidance not having a significant effect beyond the internal 
operating procedures of VA (see FAR 1.301(b)) and which will be moved 
to the VAAM. It contains a delegation of authority for Contracting 
Officers to make determinations regarding terms and conditions for 
payment for commercial items and whether they are appropriate, 
customary, and in the best interest of the Government.
    We propose to amend subsection 832.202-1, Policy, to make the 
paragraph comport with the corresponding FAR coverage, to reflect that 
Heads of Contracting Activities (HCAs) shall report no later than 
December 31 of each calendar year, to the Senior Procurement Executive 
(SPE) and Deputy Senior Procurement Executive (DSPE), on the number of 
contracts for commercial items with unusual contract financing, 
commercial interim or advance payments that were approved for the 
previous fiscal year (1 October 20XX-30 September 20XX). This would 
stipulate what is to be included in the report, the amount of such 
unusual contracting financing, commercial interim or advance payments 
that were approved, and the kind and amount of security obtained by the 
contractor for the advance.
    We propose to amend subsection 832.202-4, Security for Government 
financing, to make the paragraphs comport with the corresponding FAR 
coverage, and to delete the mention of a Dun and Bradstreet report.
    In subpart 832.4, Advance Payments for Non-Commercial Items, we 
propose to amend 832.402, General, to provide updated and revised VA 
procedures on who in the VA is delegated authority to make the 
determination described at FAR 32.402(c)(1)(iii) and to approve 
contract terms concerning advance payments. This is delegated to the 
Head of the Contracting Activity (HCA). Typically VA delegations are 
contained in the VAAM but here, where it may impact the use and 
approval of unique financing arrangements that contractors may need to 
be aware of, the delegation is being retained in the VAAR.
    We propose to amend section 832.404, Exclusions, to renumber the

[[Page 12925]]

paragraphs so it better comports with the FAR coverage and to clarify 
language and the citation of the authorities listed. We include 
information regarding the applicability of 31 U.S.C. 3324(d)(2), which 
allows VA to issue advance payment for subscriptions or other charges 
for newspapers, magazines, periodicals, and other publications for 
official use. In addition, the statutory authority is included in 
section 832.404 for 31 U.S.C. 1535, and permits the VA to issue advance 
payment for services and supplies obtained from another Government 
agency. Further, language is added that includes that as permitted by 5 
U.S.C. 4109, VA is permitted to issue advance payment for all or any 
part of the necessary expenses for training Government employees, 
including obtaining professional credentials under 5 U.S.C. 5757, in 
Government or non-Government facilities, including the purchase or 
rental of books, materials, and supplies or services directly related 
to the training of a Government employee.
    We propose to remove subparts 832.5, Progress Payments Based on 
Costs and 832.8, Assignment of Claims, as both contain internal 
procedural guidance not having a significant effect beyond the internal 
operating procedures of VA (see FAR 1.301(b)) and which will be moved 
to the VAAM.
    In subpart 832.9, Prompt Payment, we propose to revise section 
832.904, Determining payment due dates, to remove the text, but retain 
the title in the VAAR as it is related to a new proposed subsection 
that will fall underneath it. The procedures in the text will be moved 
to the VAAM as internal operational procedures of the VA.
    We propose to add subsection 832.904-70 to implement OMB Memorandum 
M-11-32, dated September 14, 2011, and to encourage making payments to 
small business contractors within 15 days of receipt of invoice.
    We propose to remove subpart 832.11, Electronic Funds Transfer, and 
section 832.1106, EFT mechanisms, as they contain internal procedural 
guidance not having a significant effect beyond the internal operating 
procedures of VA (see FAR 1.301(b)) and which will be moved to the 
VAAM.
    In subpart 832.70, Electronic Invoicing Requirements, we propose to 
amend section 832.7000, General, to reflect that the subpart contains 
policy requirements rather than procedures.
    We propose to remove section 832.7001, Definitions, since two of 
the definitions are provided in the FAR and the other relevant 
definitions have been moved to section 832.001, Definitions, which 
covers the entire part. We propose to revise the title to reflect 
``Electronic payment requests,'' and to reflect text now in section 
832.7002.
    We propose to remove section 832.7002, Electronic payment requests, 
as the content has been moved to 832.7001.
    We propose to amend subsection 832.7002-1, Data transmission, to 
renumber and redesignate it as subsection 832.7001-1; to remove the 
website address from paragraph (a); to require the address to be 
provided in the contract; and to delete from paragraph (b) a website 
which may in time become obsolete.
    We propose to amend subsection 832.7002-2, Contract clause, to 
renumber and redesignate it as subsection 832.7001-2. We also propose 
to add a stipulation to the prescription that the clause does not apply 
to contracts paid with the Governmentwide commercial purchase card.

VAAR Part 852--Solicitation Provisions and Contract Clauses

    In part 852, we propose to amend the authority by adding 41 U.S.C. 
1303 to include an updated positive law codification, to reflect 
additional authority of the VA as an executive agency to issue 
regulations that are essential to implement Governmentwide policies and 
procedures in the agency, as well as to issue additional policies and 
procedures required to satisfy the specific needs of the VA.
    We propose to amend section 852.211-70, Service data manuals, and 
to revise the title to read, ``Equipment Operation and Maintenance 
Manuals.'' This requires Contracting Officers to insert this revised 
clause in solicitations for technical medical equipment and devices, 
and/or other technical and mechanical equipment where the requiring 
activity determines manuals are a necessary requirement for operation 
and maintenance of the equipment. It removes the prior extensive 
detailed list of specific information that would need to be developed 
and instead relies on existing commercial industry practices to provide 
already developed commercial manuals.
    We propose to remove subsection 852.211-71, Special Notice, as it 
is redundant to guidance contained in the FAR.
    We propose to amend subsection 852.211-72, Technical industry 
standards, to more clearly set forth the requirements that the 
contractor shall conform to the standards reflected in the clause. It 
also requires the contractor to submit proof of conformance to the 
standard, how to obtain the standards and requires the offeror to 
contact the Contracting Officer if a response is not received within 
two weeks of the offeror's request.
    We propose to remove subsections 852.211-73, Brand Name or Equal; 
852.211-74, Liquidated Damages; and 852.211-75, Product Specifications, 
as they are all redundant to guidance contained in the FAR.
    Also in part 852, we propose to add clause 852.232-70, Payments 
under fixed-price construction contracts (without NAS-CPM). This clause 
was formerly 852.236-82, Payments under fixed-price construction 
contracts (without NAS). This clause is revised to renumber it to 
852.232-70 to reflect its prescription under part 832, and to revise 
the title of the ``NAS'' to ``NAS-CPM,'' to clarify the list of 
conditions in paragraph (c) for allowing progress payments for stored 
supplies and equipment, and to add a new paragraph (f) requiring notice 
to the contractor if retainage is to be made on a progress payment.
    We propose to add clause 852.232-71, Payments under fixed-price 
construction contracts (including NAS-CPM). This clause was formerly 
852.236-83, Payments under fixed-price construction contracts 
(including NAS). This clause is revised to renumber it as 852.232-71 to 
agree with its prescription in Part 832, to revise the title of the 
``NAS'' to ``NAS-CPM,'' and to clarify the list of conditions in 
paragraph (c) for allowing progress payments for stored supplies and 
equipment, and to add a new paragraph (f) requiring notice to the 
contractor if retainage is to be made on a progress payment.
    We propose to amend clause 852.232-72, Electronic Submission of 
Payment Requests, to revise the definition of ``designated agency 
office,'' and to delete a website address and system specifications.
    We propose to delete the clauses 852.236-82, Payments Under Fixed-
Price Construction Contracts (without NAS), and 852.236-83, Payments 
Under Fixed-Price Construction Contracts (including NAS) as they have 
been renumbered to comport with FAR arrangements and more properly 
belong in VAAR part 832 as noted above.

VAAR Part 870--Special Procurement Controls

    We propose to remove section 870.112, Telecommunications equipment, 
as it contains the

[[Page 12926]]

prescription and requirement for review of descriptive literature 
required by the clause 852.211-71, Special notice, which is proposed 
for removal as noted elsewhere in the preamble.
    We propose to remove section 870.113, Paid use of conference 
facilities, as it contains internal procedural guidance not having a 
significant effect beyond the internal operating procedures of VA (see 
FAR 1.301(b)) and which will be moved to the VAAM.

Effect of Rulemaking

    Title 48, Federal Acquisition Regulations System, Chapter 8, 
Department of Veterans Affairs, of the Code of Federal Regulations, as 
proposed to be revised by this rulemaking, would represent VA's 
implementation of its legal authority and publication of the Department 
of Veterans Affairs Acquisition Regulation (VAAR) for the cited 
applicable parts. Other than future amendments to this rule or 
governing statutes for the cited applicable parts, or as otherwise 
authorized by approved deviations or waivers in accordance with Federal 
Acquisition Regulation (FAR) subpart 1.4, Deviations from the FAR, and 
as implemented by VAAR subpart 801.4, Deviations from the FAR or VAAR, 
no contrary guidance or procedures would be authorized. All existing or 
subsequent VA guidance would be read to conform with the rulemaking if 
possible or, if not possible, such guidance would be superseded by this 
rulemaking as pertains to the cited applicable VAAR parts.

Executive Order 12866, 13563 and 13771

    Executive Orders (E.O.) 12866 and 13563 direct agencies to assess 
all costs and benefits of available regulatory alternatives and, if 
regulation is necessary, to select regulatory approaches that maximize 
net benefits (including potential economic, environmental, public 
health and safety effects, distributive impacts, and equity). E.O. 
13563 emphasizes the importance of quantifying both costs and benefits 
of reducing costs, of harmonizing rules, and of promoting flexibility. 
E.O. 12866, Regulatory Planning and Review defines ``significant 
regulatory action'' to mean any regulatory action that is likely to 
result in a rule that may: ``(1) Have an annual effect on the economy 
of $100 million or more or adversely affect in a material way the 
economy, a sector of the economy, productivity, competition, jobs, the 
environment, public health or safety, or State, local, or tribal 
governments or communities; (2) Create a serious inconsistency or 
otherwise interfere with an action taken or planned by another agency; 
(3) Materially alter the budgetary impact of entitlements, grants, user 
fees, or loan programs or the rights and obligations of recipients 
thereof; or (4) Raise novel legal or policy issues arising out of legal 
mandates, the President's priorities, or the principles set forth in 
this Executive order.''
    VA has examined the economic, interagency, budgetary, legal, and 
policy implications of this regulatory action, and it has been 
determined this rule is not a significant regulatory action under E.O. 
12866.
    VA's impact analysis can be found as a supporting document at 
http://www.regulations.gov, usually within 48 hours after the 
rulemaking document is published. Additionally, a copy of the 
rulemaking and its impact analysis are available on VA's website at 
http://www.va.gov/orpm by following the link for VA Regulations 
Published from FY 2004 Through Fiscal Year to Date. This proposed rule 
is expected to be an E.O. 13771 deregulatory action. Details on the 
estimated cost savings of this proposed rule can be found in the rule's 
economic analysis.

Paperwork Reduction Act (PRA)

    This proposed rule impacts seven existing information collection 
requirements associated with six Office of Management and Budget (OMB) 
control number approvals. The proposed actions in this rule result in 
multiple actions affecting some of these information collections, such 
as: the proposed outright removal of the information collection; no 
change in information collection burdens although titles and numbers 
may be changed or the clauses moved to other parts of the VAAR; a 
reduction in existing information collection burdens; and the proposed 
redesignation of the existing approved OMB collection numbers and the 
associated burden as a result of two clauses we propose to both retitle 
and renumber.
    The Paperwork Reduction Act of 1995 (at 44 U.S.C. 3507) requires 
that VA consider the impact of paperwork and other information 
collection burdens imposed on the public. Under 44 U.S.C. 3507(a), an 
agency may not collect or sponsor the collection of information, nor 
may it impose an information collection requirement unless it displays 
a currently valid OMB control number. See also 5 CFR 1320.8(b)(3)(vi).
    This proposed rule would impose the following amended information 
collection requirements to two of the six existing information 
collection approval numbers associated with this proposed rule. 
Although this action contains provisions constituting collections of 
information at 48 CFR 852.236-82 and 852.236-83, under the provisions 
of the Paperwork Reduction Act (44 U.S.C. 3501-3521), no new proposed 
collections of information are associated with these clauses. The 
information collection requirements for 48 CFR 852.236-82 and 852.236-
83 are currently approved by the Office of Management and Budget (OMB) 
and have been assigned OMB control number 2900-0422. However, this 
information collection has been submitted to OMB to revise the title 
and to redesignate and renumber the two clauses currently numbered as 
sections 852.236-82, Payments Under Fixed-Price Construction Contracts 
(without NAS), and 852.236-83, Payments Under Fixed-Price Construction 
Contracts (including NAS). Accordingly, if approved, they would reflect 
the new designation and revised titles as set forth in the preamble and 
the amendatory language of this proposed rule to read: 852.232-70, 
Payments Under Fixed-Price Construction Contracts (without NAS-CPM), 
and 852.232-71, Payments Under Fixed-Price Construction Contracts 
(including NAS-CPM), respectively, under the associated OMB control 
number 2900-0422. The references to the old numbers--852.236-82 and 
852.236-83, would accordingly be removed. There is no change in the 
information collection burden that is associated with this proposed 
request. As required by the Paperwork Reduction Act of 1995 (at 44 
U.S.C. 3507(d)), VA has submitted these information collection 
amendments to OMB for its review. Notice of OMB approval for this 
information collection will be published in a future Federal Register 
document.
    This proposed rule would impose the following amended information 
collection requirements to one of the six existing information 
collection approval numbers associated with this proposed rule. 
Although this action contains provisions constituting collections of 
information at 48 CFR 852.211-70, Service data manuals, under the 
provisions of the Paperwork Reduction Act (44 U.S.C. 3501-3521), no new 
proposed information collection is associated with this clause. The 
information collection requirement for 48 CFR 852.211-70 is currently 
approved by OMB and has been assigned OMB control number 2900-0587. 
However, this information collection has been submitted to OMB

[[Page 12927]]

to revise the title from ``Service Data Manuals,'' to read, ``Equipment 
Operation and Maintenance Manuals.'' We propose to reflect the revised 
title as set forth in the preamble and the amendatory language of this 
proposed rule for this clause to read: 852.211-70, Equipment Operation 
and Maintenance Manuals, under the associated OMB control number 2900-
0587. We propose to remove the reference in the existing OMB control 
number to the old title. There is also a reduction in the information 
collection burden that is associated with this proposed request. The 
previously approved estimated annual hourly burden is 621 hours. As a 
result of revising the clause and removing the requirement to develop 
Government-specified service manuals, the VA has eliminated an 
unnecessary burden on the public by making use of commercial operation 
and maintenance manuals just like the general public and established 
commercial practices, thereby reducing by half the estimated annual 
hourly burden which is now estimated at 311 hours, a reduction of 310 
annual hours. As required by the Paperwork Reduction Act of 1995 (at 44 
U.S.C. 3507(d)), VA has submitted this information collection amendment 
to OMB for its review. Notice of OMB approval for this information 
collection will be published in a future Federal Register document.
    This proposed rule would remove two of the six existing information 
collection requirements associated with this action at 48 CFR 852.211-
71, Special Notice, and 48 CFR 852.211-73, Brand Name or Equal. Under 
the provisions of the Paperwork Reduction Act (44 U.S.C. 3501-3521), it 
discontinues the associated corresponding approved OMB control numbers, 
2900-0588 and 2900-0585, respectively. As a result of this proposed 
rule, there is a removal in the information collection burden that is 
associated with the removal of these two information collection 
requirements. For 48 CFR 852.211-71, Special Notice, and its 
corresponding OMB control number 2900-0588, this results in a removal 
of 875 estimated annual burden hours. For 48 CFR 852.211-73, Brand Name 
or Equal, and its corresponding OMB control number 2900-0585, this 
results in a removal of 1,125 estimated annual burden hours. As 
required by the Paperwork Reduction Act of 1995 (at 44 U.S.C. 3507(d)), 
VA has submitted this information collection amendment to OMB for its 
review. Notice of OMB approval for this information collection will be 
published in a future Federal Register document.
    This proposed rule also contains two other provisions constituting 
a collection of information at 48 CFR 852.211-72, Technical industry 
standards, and 48 CFR 832.202-4, Security for Government financing, 
which remain unchanged. Under the provisions of the Paperwork Reduction 
Act of 1995 (44 U.S.C. 3501-3521), no new or proposed revised 
collection of information is associated with these provisions as a part 
of this proposed rule. The information collection requirements for 48 
CFR 852.211-72 and 48 CFR 832.202-4 are currently approved by the OMB 
and have been assigned OMB control numbers 2900-0586 and 2900-0688, 
respectively. The burden of these information collections remains 
unchanged. In accordance with the Paperwork Reduction Act of 1995 (44 
U.S.C. 3501-3521), the OMB has approved the reporting or recordkeeping 
provisions that are included in the clause and the text under section 
832.202-4 cited above and has given the VA the following approval 
numbers: OMB 2900-0586 and OMB 2900-0688, respectively.

Regulatory Flexibility Act

    This proposed rule would not have a significant economic impact on 
a substantial number of small entities as they are defined in the 
Regulatory Flexibility Act, 5 U.S.C. 601-612. The overall impact of the 
proposed rule would be of benefit to small businesses owned by Veterans 
or service-disabled Veterans as the VAAR is being updated to remove 
extraneous procedural information that applies only to VA's internal 
operating procedures. VA is merely adding existing and current 
regulatory requirements to the VAAR and removing any guidance that is 
applicable only to VA's internal operation processes or procedures. VA 
estimates no cost impact to individual business would result from these 
rule updates. This rulemaking does not change VA's policy regarding 
small businesses, does not have an economic impact to individual 
businesses, and there are no increased or decreased costs to small 
business entities. On this basis, the proposed rule would not have an 
economic impact on a substantial number of small entities as they are 
defined in the Regulatory Flexibility Act, 5 U.S.C. 601-612. Therefore, 
under 5 U.S.C. 605(b), this regulatory action is exempt from the 
initial and final regulatory flexibility analysis requirements of 
sections 603 and 604.

Unfunded Mandates

    The Unfunded Mandates Reform Act of 1995 requires, at 2 U.S.C. 
1532, that agencies prepare an assessment of anticipated costs and 
benefits before issuing any rule that may result in the expenditure by 
State, local, and tribal Governments, in the aggregate, or by the 
private sector, of $100 million or more (adjusted annually for 
inflation) in any one year. This proposed rule would have no such 
effect on State, local, and tribal Governments or on the private 
sector.

List of Subjects

48 CFR Part 801

    Administrative practice and procedure, Government procurement, 
Reporting and recordkeeping requirements.

48 CFR Part 811and 832

    Government procurement.

48 CFR Part 852

    Government procurement, Reporting and recordkeeping requirements.

48 CFR Part 870

    Asbestos, Frozen foods, Government procurement, Telecommunications.

Signing Authority

    The Secretary of Veterans Affairs, or designee, approved this 
document and authorized the undersigned to sign and submit the document 
to the Office of the Federal Register for publication electronically as 
an official document of the Department of Veterans Affairs. Gina S. 
Farrisee, Deputy Chief of Staff, Department of Veterans Affairs, 
approved this document on August 7, 2017, for publication.

    Dated: February 22, 2018.
Consuela Benjamin,
Office of Regulation Policy & Management, Office of the Secretary, 
Department of Veterans Affairs.
    For the reasons set out in the preamble, VA proposes to amend 48 
CFR, chapter 8, parts 801, 811, 832, 852, and 870 as follows:

PART 801--DEPARTMENT OF VETERANS AFFAIRS ACQUISITION REGULATION 
SYSTEM

0
1. The authority citation for part 801 is revised to read as follows:

    Authority: 40 U.S.C. 121(c); 41 U.S.C. 1121; 41 U.S.C. 1303; 41 
U.S.C. 1702; and 48 CFR 1.301-1.304.

Subpart 801.1--Purpose, Authority, Issuance 801.106 [Amended]

0
2. Amend the section 801.106 table columns titled ``48 CFR part or 
section where identified and described'' and ``Current OMB control 
number'' to--
0
a. Remove the reference to section 832.006-4 and OMB Control Number 
2900-0668.

[[Page 12928]]

0
b. Remove the reference to section 852.211-71 and OMB Control Number 
2900-0588.
0
c. Remove the reference to section 852.211-73 and OMB Control Number 
2900-0585.
0
d. Remove ``852.236-82 through'';.
0
e. Add the reference to sections 852.232-70 and 852.232-71 and OMB 
control number 2900-0422 on the same line.
* * * * *

SUBCHAPTER B--[Amended]

0
3. The title of subchapter B is revised to read as follows:

SUBCHAPTER B--ACQUISITION PLANNING

PART 811--DESCRIBING AGENCY NEEDS

0
4. The authority citation for part 811 is revised to read as follows:

    Authority: 40 U.S.C. 121(c); 41 U.S.C. 1303; 41 U.S.C. 1702; and 
48 CFR 1.301-1.304.


Sec.  811.001  [Removed]

0
5. Section 811.001 is removed.
0
6. Revise subpart 811.1 to read as follows:

Subpart 811.1--Selecting and Developing Requirements Documents


Sec.  811.107-70  Contract clause.

    The Contracting Officer shall insert the clause at 852.211-70, 
Equipment Operation and Maintenance Manuals, in solicitations and 
contracts for technical medical, and other technical and mechanical 
equipment and devices where the requiring activity determines manuals 
are a necessary requirement for operation and maintenance of the 
equipment.
0
7. Revise subpart 811.2 to read as follows:

Subpart 811.2--Using and Maintaining Requirements Documents


Sec.  811.204-70  Contract clause.

    The Contracting Officer shall insert the clause at 852.211-72, 
Technical industry Standards, in solicitations and contracts requiring 
conformance to technical industry standards, federal specifications, 
standards and commercial item descriptions unless comparable coverage 
is included in the item specification.

Subpart 811.4--[Removed and reserved].

0
8. Subpart 811.4 is removed and reserved.

Subpart 811.5-- Removed and reserved]

0
9. Subpart 811.5 is removed and reserved.

Subpart 811.6--[Removed and reserved]

0
10. Subpart 811.6 is removed and reserved.

PART 832--CONTRACT FINANCING

0
11. The authority citation for part 832 is revised to read as follows:

    Authority: 40 U.S.C. 121(c); 41 U.S.C. 1303; 41 U.S.C. 1702; and 
48 CFR 1.301-1.304.

0
12. Section 832.001 is added to read as follows:


Sec.  832.001  Definitions.

    As used in this subpart:
    (a) Designated agency office means the office designated by the 
purchase order, agreement, or contract to first receive and review 
invoices. This office can be contractually designated as the receiving 
entity. This office may be different from the office issuing the 
payment.
    (b) Electronic form means an automated system transmitting 
information electronically according to the accepted electronic data 
transmission methods identified in 832.7002-1. Facsimile, email, and 
scanned documents are not acceptable electronic forms for submission of 
payment requests.
    (c) Payment request means any request for contract financing 
payment or invoice payment submitted by a contractor under a contract.
0
13. Revise section 832.006-1 to read as follows:


Sec.  832.006-1  General.

    (b) The Senior Procurement Executive (SPE) is authorized to make 
determinations that there is substantial evidence that contractors' 
requests for advance, partial, or progress payments are based on fraud 
and may direct that further payments to the contractors be reduced or 
suspended, as provided in FAR 32.006.


Sec.  832.006-2  [Removed].


Sec.  832.006-3  [Removed].

0
14. Remove sections 832.006-2 and 832.006-3.
0
15. Section 832.006-4 is revised to read as follows:


Sec.  832.006-4  Procedures.

    (b) The Remedy Coordination Official (RCO) for VA is the Deputy 
Senior Procurement Executive (DSPE) and shall carry out the 
responsibilities of the Secretary or designee in FAR 32.006-4(b). To 
determine whether substantial evidence exists that the request for 
payment under a contract is based on fraud.
    (e) The RCO shall carry out the responsibilities of the agency head 
in FAR 32.006-4(e) to notify the contractor of the reasons for the 
recommended action and of its right to submit information within a 
reasonable period of time in response to the proposed action under FAR 
32.006.
    (1) The notice of proposed action will be sent to the last known 
address of the contractor, the contractor's counsel, or agent for 
service of process, by certified mail, return receipt requested, or any 
other method that provides signed evidence of receipt. In the case of a 
business, the notice of proposed action may be sent to any partner, 
principal, officer, director, owner or co-owner, or joint venture. The 
contractor will be afforded an opportunity to appear before the RCO to 
present information or argument in person or through a representative 
and may supplement the oral presentation with written information and 
argument.
    (2) The contractor may supplement the oral presentation with 
written information and argument. The proceedings will be conducted in 
an informal manner and without the requirement for a transcript. If the 
RCO does not receive a reply from the contractor within 30 calendar 
days, the RCO will base his or her recommendations on the information 
available. Any recommendation of the RCO under FAR 31.006-4(a) and 
paragraph (b) of this section, must address the results of this 
notification and the information, if any, provided by the contractor. 
After reviewing all the information, the RCO shall make a 
recommendation to the SPE whether or not substantial evidence of fraud 
exists.
    (g) In addition to following the procedures in FAR 32.006-4, the 
SPE shall provide a copy of each final determination and the supporting 
documentation to the contractor, the RCO, the Contracting Officer, and 
the OIG. The Contracting Officer will place a copy of the determination 
and the supporting documentation in the contract file.

Subpart 832.1--Non-Commercial Item Purchase Financing

0
16. Section 832.111 is revised to read as follows:

[[Page 12929]]

Sec.  832.111-70  VA contract clauses for non-commercial purchases.

    (a)(1) Insert the clause at 852.232-70, Payments under fixed-price 
construction contracts (without NAS-CPM) in solicitations and contracts 
that contain the FAR clause at 52.232-5, Payments Under Fixed-Price 
Construction Contracts, and if the solicitation or contract does not 
require use of the ``Network Analysis System--Critical Path Method 
(NAS-CPM).''
    (2) If the solicitation or contract includes guarantee period 
services, the Contracting Officer shall use the clause with its 
Alternate I.
    (b)(1) Insert the clause at 852.232-71, Payments under fixed-price 
construction contracts (including NAS-CPM), in solicitations and 
contracts that contain the FAR clause at 52.232-5, Payments Under 
Fixed-Price Construction Contracts, and if the solicitation or contract 
requires use of the ``Network Analysis System--Critical Path Method 
(NAS-CPM).''
    (2) If the solicitation or contract includes guarantee period 
services, the Contracting Officer shall use the clause with its 
Alternate I.

Subpart 832.2--Commercial Item Purchase Financing


Sec.  832.201  [Removed].

0
17. Section 832.201 is removed.
0
18. Section 832.202-1 is revised to read as follows:


Sec.  832.202-1  Policy.

    (d) HCAs shall report, no later than December 31st of each calendar 
year, to the Senior Procurement Executive (SPE) and the DSPE, on the 
number of contracts for commercial items with unusual contract 
financing or with commercial interim or advance payments approved for 
the previous fiscal year. The report shall include the contract number 
and amount, the amount of the unusual contract financing or with 
commercial interim or advance payments approved, and the kind and 
amount of security obtained for the advance.
0
19. Section 832.202-4 is revised to read as follows:


Sec.  832.202-4  Security for Government financing.

    (a)(2) An offeror's financial condition may be considered adequate 
security to protect the Government's interest when the Government 
provides contract financing. In assessing the offeror's financial 
condition, the Contracting Officer may obtain, to the extent required, 
the following information--
    (i) A current year interim balance sheet and income statement and 
balance sheets and income statements for the two preceding fiscal 
years. The statements should be prepared in accordance with generally 
accepted accounting principles and must be audited and certified by an 
independent public accountant or an appropriate officer of the firm;
    (ii) A cash flow forecast for the remainder of the contract term 
showing the planned origin and use of cash within the firm or branch 
performing the contract;
    (iii) Information on financing arrangements disclosing the 
availability of cash to finance contract performance, the contractor's 
exposure to financial risk, and credit arrangements;
    (iv) A statement of the status of all State, local, and Federal tax 
accounts, including any special mandatory contributions;
    (v) A description and explanation of the financial effects of any 
leases, deferred purchase arrangements, patent or royalty arrangements, 
insurance, planned capital expenditures, pending claims, contingent 
liabilities, and other financial aspects of the business; and
    (vi) Any other financial information deemed necessary.

Subpart 832.4--Advance Payments for Non-Commercial Items

0
20. Section 832.402 is revised to read as follows:


Sec.  832.402  General.

    (c)(1)(iii) The authority to make the determination required by FAR 
32.402(c)(1)(iii) and to approve contract terms is delegated to the 
head of the contracting activity (HCA). The request for approval shall 
include the information required by FAR 32.409-1 and shall address the 
standards for advance payment in FAR 32.402(c)(2). HCAs shall report, 
no later than December 31st of each calendar year, to the Senior 
Procurement Executive (SPE) and the DSPE, on number of contracts for 
non-commercial items with advance payments approved in the previous 
fiscal year. The report shall include the contract number and amount, 
the amount of the advance payment, and the kind and amount of security 
obtained for the advance.
0
21. Amend section 832.404 by revising paragraph (b) to read as follows:


Sec.  832.404  Exclusions.

* * * * *
    (b)(1) As permitted by 31 U.S.C. 3324(d)(2), VA allows advance 
payment for subscriptions or other charges for newspapers, magazines, 
periodicals, and other publications for official use, notwithstanding 
the provisions of 31 U.S.C. 3324(a). The term ``other publications'' 
includes any publication printed, microfilmed, photocopied or 
magnetically or otherwise recorded for auditory or visual use.
    (2) As permitted by 31 U.S.C. 1535, VA allows advance payment for 
services and supplies obtained from another Government agency.
    (3) As permitted by 5 U.S.C. 4109, VA allows advance payment for 
all or any part of the necessary expenses for training Government 
employees, including obtaining professional credentials under 5 U.S.C. 
5757, in Government or non-Government facilities, including the 
purchase or rental of books, materials, and supplies or services 
directly related to the training of a Government employee.
* * * * *

Subpart 832.5--5 [Removed and reserved].

0
22. Subpart 832.5 is removed and reserved.

Subpart 832.8 [Removed and reserved].

0
23. Subpart 832.8 is removed and reserved.

Subpart 832.9--Prompt Payment


Sec.  832.904  [Redesignated as 832.904-70].

0
24. Redesignate section 832.904 as 832.904-70 and revise newly 
redesignated section 832.904-70 to read as follows:


Sec.  832.904-70  Determining payment due dates for small businesses.

    Pursuant to Office of Management and Budget Memorandum M-11-32, 
dated September 14, 2011, Contracting Officers shall, to the full 
extent permitted by law, make payments to small business contractors as 
soon as practicable, with the goal of making payments within 15 days of 
receipt of a proper invoice and confirmation that the goods and 
services have been received and accepted by the Federal Government.


Sec.  832.11  [Removed and reserved].

0
25. Subpart 832.11 is removed and reserved.
0
26. Revise subpart 832.70 to read as follows:

Subpart 832.70--Electronic Invoicing Requirements

Sec
832.7000 General
832.7001 Electronic payment requests
832.7001-1 Data transmission
832.7001-2 Contract clause

[[Page 12930]]

Sec.  832.7000  General.

    This subpart prescribes policy requirements for submitting and 
processing payment requests in electronic form.


Sec.  832.7001  Electronic payment requests.

    (a) The contractor shall submit payment requests in electronic form 
unless directed by the Contracting Officer to submit payment requests 
by mail. Purchases paid with a Government-wide commercial purchase card 
are considered to be an electronic transaction for purposes of this 
rule, and therefore no additional electronic invoice submission is 
required.
    (b) The Contracting Officer may direct the contractor to submit 
payment requests by mail, through the United States Postal Service, to 
the designated agency office for--
    (1) Awards made to foreign vendors for work performed outside the 
United States;
    (2) Classified contracts or purchases when electronic submission 
and processing of payment requests could compromise the safeguarding of 
classified or privacy information;
    (3) Contracts awarded by Contracting Officers in the conduct of 
emergency operations, such as responses to national emergencies;
    (4) Solicitations or contracts in which the designated agency 
office is a VA entity other than the VA Financial Services Center in 
Austin, Texas; or
    (5) Solicitations or contracts in which the VA designated agency 
office does not have electronic invoicing capability as described 
above.


Sec.  832.7001-1  Data transmission.

    The contractor shall submit electronic payment requests through--
    (a) VA's Electronic Invoice Presentment and Payment System at the 
current website address provided in the contract; or
    (b) A system that conforms to the X12 electronic data interchange 
(EDI) formats established by the Accredited Standards Center (ASC) 
chartered by the American National Standards Institute (ANSI).


Sec.  832.7001-2  Contract clause.

    The Contracting Officer shall insert the clause at 852.232-72, 
Electronic submission of payment requests, in solicitations and 
contracts exceeding the micro-purchase threshold, except those for 
which the Contracting Officer has directed otherwise under 832.7001, 
and those paid with a Governmentwide commercial purchase card.

PART 852--SOLICITATION PROVISIONS AND CONTRACT CLAUSES

0
27. The authority citation for part 852 is revised to read as follows:

    Authority: 38 U.S.C. 8127-8128, and 8151-8153; 40 U.S.C. 121(c); 
41 U.S.C. 1303; 41 U.S.C. 1702; and 48 CFR 1.301-1.304.

Subpart 852.2--Text of Provisions and Clauses

0
28. Section 852.211-70 is revised to read as follows:


Sec.  852.211-70  Equipment Operation and Maintenance Manuals.

    As prescribed in 811.107-70, insert the following clause:

EQUIPMENT OPERATION AND MAINTENANCE MANUALS (DATE)

    The contractor shall follow standard commercial practices to 
furnish manual(s), handbook(s) or brochure(s) containing operation, 
installation, and maintenance instructions, including pictures or 
illustrations, schematics, and complete repair/test guides, as 
necessary, for technical medical equipment and devices, and/or other 
technical and mechanical equipment provided per CLIN(s) # 
(Contracting Officer insert CLIN information). The manuals, 
handbooks or brochures shall be provided in hard copy, soft copy or 
with electronic access instructions, consistent with standard 
industry practices for the equipment or device. Where applicable, 
the manuals, handbooks or brochures will include electrical data and 
connection diagrams for all utilities. The documentation shall also 
contain a complete list of all replaceable parts showing part 
number, name, and quantity required.


(End of clause)


Sec.  852.211-71  [Removed and reserved].

0
29. Section 852.211-71 is removed and reserved.
0
30. Section 852.211-72 is revised to read as follows:


Sec.  852.211-72  Technical Industry Standards.

    As prescribed in 811.204-70, insert the following clause:

TECHNICAL INDUSTRY STANDARDS (DATE)

    (a) The contractor shall conform to the standards established 
by: (Contracting Officer: Insert name of organization establishing 
the requirement, reference title, cite and date, e.g., United States 
Department of Agriculture (USDA), Institutional Meat Purchase 
Specifications (IMPS), Series 100, Beef products, Jan 2010) as to 
(Contracting Officer: Insert item and CLIN, e.g. CLIN 0005 Ground 
Beef).
    (b) The contractor shall submit proof of conformance to the 
standard. This proof may be a label or seal affixed to the equipment 
or supplies, warranting that the item(s) have been tested in 
accordance with the standards and meet the contract requirement. 
Proof may also be furnished by the organization listed above 
certifying that the item(s) furnished have been tested in accordance 
with and conform to the specified standards.
    (c) Offerors may obtain the standards cited in this provision by 
submitting a request, including the solicitation number, title and 
number of the publication to: (Organization)__ (Mail or email 
address) __
    (d) The offeror shall contact the Contracting Officer if 
response is not received within two weeks of the request.


(End of clause)


Sec.  852.211-73  [Removed and reserved].


Sec.  852.211-74  [Removed and reserved].


Sec.  852.211-75  [Removed and reserved].

0
31. Remove and reserve sections 852.211-73 through 852.211-75.
0
32. Add section 852.232-70 to read as follows:


Sec.  852.232-70  Payments under fixed-price construction contracts 
(without NAS-CPM).

    As prescribed in 832.111-70, insert the following clause in 
contracts that do not contain a section entitled ``Network Analysis 
System--Critical Path Method (without NAS-CPM)''

Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) 
(Date)

    The clause FAR 52.232-5, Payments under Fixed-Price Construction 
Contracts, is implemented as follows:
    (a) Retainage.
    (1) The Contracting officer may retain funds--
    (i) Where performance under the contract has been determined to 
be deficient or the Contractor has performed in an unsatisfactory 
manner in the past; or
    (ii) As the contract nears completion, to ensure that 
deficiencies will be corrected and that completion is timely.
    (2) Examples of deficient performance justifying a retention of 
funds include, but are not restricted to, the following--
    (i) Unsatisfactory progress as determined by the Contracting 
Officer;
    (ii) Failure to meet schedule in Schedule of Work Progress;
    (iii) Failure to present submittals in a timely manner; or
    (iv) Failure to comply in good faith with approved 
subcontracting plans, certifications, or contract requirements.
    (3) Any level of retention shall not exceed 10 percent either 
where there is determined to be unsatisfactory performance, or when 
the retainage is to ensure satisfactory completion. Retained amounts 
shall be paid promptly upon completion of all contract requirements, 
but nothing contained in this subparagraph shall be construed as 
limiting the Contracting Officer's right to withhold funds under 
other provisions of the contract or in accordance with the general 
law and

[[Page 12931]]

regulations regarding the administration of Government contracts.
    (b) The Contractor shall submit a schedule of cost to the 
Contracting Officer for approval within 30 calendar days after date 
of receipt of notice to proceed. Such schedule will be signed and 
submitted in triplicate. The approved cost schedule will be one of 
the bases for determining progress payments to the Contractor for 
work completed. This schedule shall show cost by the work activity/
event for each building or unit of the contract, as instructed by 
the resident engineer.
    (1) The work activities/events shall be subdivided into as many 
sub-activities/events as are necessary to cover all component parts 
of the contract work.
    (2) Costs as shown on this schedule must be true costs and the 
resident engineer may require the Contractor to submit the original 
estimate sheets or other information to substantiate the detailed 
makeup of the schedule.
    (3) The sums of the sub-activities/events, as applied to each 
work activity/event, shall equal the total cost of such work 
activity/event. The total cost of all work activities/events shall 
equal the contract price.
    (4) Insurance and similar items shall be prorated and included 
in the cost of each branch of the work.
    (5) The cost schedule shall include separate cost information 
for the systems listed in the table in this subparagraph (b)(5). The 
percentages listed below are proportions of the cost listed in the 
Contractor's cost schedule and identify, for payment purposes, the 
value of the work to adjust, correct and test systems after the 
material has been installed. Payment of the listed percentages will 
be made only after the Contractor has demonstrated that each of the 
systems is substantially complete and operates as required by the 
contract.

           Value of Adjusting, Correcting, and Testing System
------------------------------------------------------------------------
                         System                               Percent
------------------------------------------------------------------------
Pneumatic tube system...................................              10
Incinerators (medical waste and trash)..................               5
Sewage treatment plant equipment........................               5
Water treatment plant equipment.........................               5
Washers (dish, cage, glass, etc.).......................               5
Sterilizing equipment...................................               5
Water distilling equipment..............................               5
Prefab temperature rooms (cold, constant temperature)...               5
Entire air-conditioning system (Specified under 600                    5
 Sections)..............................................
Entire boiler plant system (Specified under 700                        5
 Sections)..............................................
General supply conveyors................................              10
Food service conveyors..................................              10
Pneumatic soiled linen and trash system.................              10
Elevators and dumbwaiters...............................              10
Materials transport system..............................              10
Engine-generator system.................................               5
Primary switchgear......................................               5
Secondary switchgear....................................               5
Fire alarm system.......................................               5
Nurse call system.......................................               5
Intercom system.........................................               5
Radio system............................................               5
TV (entertainment) system...............................               5
------------------------------------------------------------------------

    (c) In addition to this cost schedule, the Contractor shall 
submit such unit costs as may be specifically requested. The unit 
costs shall be those used by the Contractor in preparing its bid and 
will not be binding as pertaining to any contract changes.
    (d) The Contracting Officer will consider for monthly progress 
payments material and/or equipment procured by the Contractor and 
stored on the construction site, as space is available, or at a 
local approved location off the site, under such terms and 
conditions as the Contracting Officer approves, including but not 
limited to the following--
    (1) The materials or equipment are in accordance with the 
contract requirements and/or approved samples and shop drawings;
    (2) The materials and/or equipment are approved by the resident 
engineer;
    (3) The materials and/or equipment are stored separately and are 
readily available for inspection and inventory by the resident 
engineer;
    (4) The materials and/or equipment are protected against 
weather, theft and other hazards and are not subjected to 
deterioration; and
    (5) The Contractor obtains the concurrence of its surety for 
off-site storage.
    (e) The Government reserves the right to withhold payment until 
samples, shop drawings, engineer's certificates, additional bonds, 
payrolls, weekly statements of compliance, proof of title, 
nondiscrimination compliance reports, or any other requirements of 
this contract, have been submitted to the satisfaction of the 
Contracting officer.
    (f) The Contracting Officer will notify the Contractor in 
writing within 10 calendar-days of exercising retainage against any 
payment in accordance with FAR clause 52.232-5(e). The notice shall 
disclose the amount of the retainage in value and percent retained 
from the payment, and provide explanation for the retainage.


(End of clause)

    Alternate I (DATE). If the specifications include guarantee 
period services, the Contracting officer shall include the following 
paragraphs as additions to paragraph (b) of the basic clause:
    (6)(i) The Contractor shall at the time of contract award 
furnish the total cost of the guarantee period services in 
accordance with specification section(s) covering guarantee period 
services. The Contractor shall submit, within 15 calendar days of 
receipt of the notice to proceed, a guarantee period performance 
program that shall include an itemized accounting of the number of 
work-hours required to perform the guarantee period service on each 
piece of equipment. The Contractor shall also submit the established 
salary costs, including employee fringe benefits, and what the 
contractor reasonably expects to pay over the guarantee period, all 
of which will be subject to the Contracting officer's approval.
    (ii) The cost of the guarantee period service shall be prorated 
on an annual basis and paid in equal monthly payments by VA during 
the period of guarantee. In the event the installer does not perform 
satisfactorily during this period, all payments may be withheld and 
the Contracting Officer shall inform the contractor of the 
unsatisfactory performance, allowing the contractor 10 days to 
correct deficiencies and comply with the contract. The guarantee 
period service is subject to those provisions as set forth in the 
Payments and Default clauses.

0
33. Add section 852.232-71 to read as follows:

[[Page 12932]]

Sec.  852.232-71  Payments under fixed-price construction contracts 
(including NAS-CPM).

    As prescribed in 832.111-70, insert the following clause in 
contracts that contain a section entitled ``Network Analysis System--
Critical Path Method (NAS-CPM).''

Payments Under Fixed-Price Construction Contracts (Including NAS-CPM) 
(Date)

    The clause FAR 52.232-5, Payments under Fixed-Price Construction 
Contracts, is implemented as follows:
    (a) Retainage.
    (1) The Contracting Officer may retain funds--
    (i) Where performance under the contract has been determined to 
be deficient or the Contractor has performed in an unsatisfactory 
manner in the past; or
    (ii) As the contract nears completion, to ensure that 
deficiencies will be corrected and that completion is timely.
    (2) Examples of deficient performance justifying a retention of 
funds include, but are not restricted to, the following--
    (i) Unsatisfactory progress as determined by the Contracting 
Officer;
    (ii) Failure to meet schedule in Schedule of Work Progress;
    (iii) Failure to present submittals in a timely manner; or
    (iv) Failure to comply in good faith with approved 
subcontracting plans, certifications, or contract requirements.
    (3) Any level of retention shall not exceed 10 percent either 
where there is determined to be unsatisfactory performance, or when 
the retainage is to ensure satisfactory completion. Retained amounts 
shall be paid promptly upon completion of all contract requirements, 
but nothing contained in this subparagraph shall be construed as 
limiting the Contracting Officer's right to withhold funds under 
other provisions of the contract or in accordance with the general 
law and regulations regarding the administration of Government 
contracts.
    (b) The Contractor shall submit a schedule of costs in 
accordance with the requirements of section ``Network Analysis 
System -- Critical Path Method (NAS-CPM)'' to the Contracting 
Officer for approval within 90 calendar days after date of receipt 
of notice to proceed. The approved cost schedule will be one of the 
bases for determining progress payments to the Contractor for work 
completed.
    (1) Costs as shown on this schedule must be true costs and the 
resident engineer may require the contractor to submit its original 
estimate sheets or other information to substantiate the detailed 
makeup of the cost schedule.
    (2) The total costs of all work activities/events shall equal 
the contract price.
    (3) Insurance and similar items shall be prorated and included 
in each work activity/event cost of the critical path method (CPM).
    (4) The CPM shall include a separate cost loaded activity for 
adjusting and testing of the systems listed in the table in 
paragraph (b)(5) of this section. The percentages listed below will 
be used to determine the cost of adjust and test work activities/
events and identify, for payment purposes, the value of the work to 
adjust, correct and test systems after the material has been 
installed.
    (5) Payment for adjust and test activities will be made only 
after the Contractor has demonstrated that each of the systems is 
substantially complete and operates as required by the contract.

           Value of Adjusting, Correcting, and Testing System
------------------------------------------------------------------------
                         System                               Percent
------------------------------------------------------------------------
Pneumatic tube system...................................              10
Incinerators (medical waste and trash)..................               5
Sewage treatment plant equipment........................               5
Water treatment plant equipment.........................               5
Washers (dish, cage, glass, etc.).......................               5
Sterilizing equipment...................................               5
Water distilling equipment..............................               5
Prefab temperature rooms (cold, constant temperature)...               5
Entire air-conditioning system (Specified under 600                    5
 Sections)..............................................
Entire boiler plant system (Specified under 700                        5
 Sections)..............................................
General supply conveyors................................              10
Food service conveyors..................................              10
Pneumatic soiled linen and trash system.................              10
Elevators and dumbwaiters...............................              10
Materials transport system..............................              10
Engine-generator system.................................               5
Primary switchgear......................................               5
Secondary switchgear....................................               5
Fire alarm system.......................................               5
Nurse call system.......................................               5
Intercom system.........................................               5
Radio system............................................               5
TV (entertainment) system...............................               5
------------------------------------------------------------------------

    (c) In addition to this cost schedule, the Contractor shall 
submit such unit costs as may be specifically requested. The unit 
costs shall be those used by the Contractor in preparing its bid and 
will not be binding as pertaining to any contract changes.
    (d) The Contracting Officer will consider for monthly progress 
payments material and/or equipment procured by the Contractor and 
stored on the construction site, as space is available, or at a 
local approved location off the site, under such terms and 
conditions as the Contracting Officer approves, including but not 
limited to the following--
    (1) The materials or equipment are in accordance with the 
contract requirements and/or approved samples and shop drawings;
    (2) The materials and/or equipment are approved by the resident 
engineer;
    (3) The materials and/or equipment are stored separately and are 
readily available for inspection and inventory by the resident 
engineer;
    (4) The materials and/or equipment are protected against 
weather, theft and other hazards and are not subjected to 
deterioration; and
    (5) The contractor obtains the concurrence of its surety for 
off-site storage.
    (e) The Government reserves the right to withhold payment until 
samples, shop drawings, engineer's certificates, additional bonds, 
payrolls, weekly statements of compliance, proof of title, 
nondiscrimination compliance reports, or any other requirements of 
this contract, have been submitted to the satisfaction of the 
Contracting Officer.
    (f) The Contracting Officer will notify the Contractor in 
writing within 10 calendar-days of exercising retainage against any 
payment in accordance with FAR clause 52.232-5(e). The notice shall 
disclose the amount of the retainage in value and percent retained 
from the payment, and provide explanation for the retainage.


(End of clause)

    Alternate I (DATE). If the specifications include guarantee 
period services, the Contracting officer shall include the

[[Page 12933]]

following paragraphs as additions to paragraph (b) of the basic 
clause:
    (6)(i) The Contractor shall show on the critical path method 
(CPM) the total cost of the guarantee period services in accordance 
with the guarantee period service section(s) of the specifications. 
This cost shall be priced out when submitting the CPM cost loaded 
network. The cost submitted shall be subject to the approval of the 
Contracting Officer. The activity on the CPM shall have money only 
and not activity time.
    (ii) The Contractor shall submit with the CPM a guarantee period 
performance program which shall include an itemized accounting of 
the number of work-hours required to perform the guarantee period 
service on each piece of equipment. The Contractor shall also submit 
the established salary costs, including employee fringe benefits, 
and what the contractor reasonably expects to pay over the guarantee 
period, all of which will be subject to the Contracting Officer's 
approval.
    (iii) The cost of the guarantee period service shall be prorated 
on an annual basis and paid in equal monthly payments by VA during 
the period of guarantee. In the event the installer does not perform 
satisfactorily during this period, all payments may be withheld and 
the Contracting Officer shall inform the contractor of the 
unsatisfactory performance, allowing the Contractor 10 days to 
correct and comply with the contract. The guarantee period service 
is subject to those provisions as set forth in the Payments and 
Default clauses.

0
34. Section 852.232-72 is revised to read as follows:


Sec.  852.232-72  Electronic submission of payment requests.

    As prescribed in 832.7001-2, insert the following clause:

Electronic Submission of Payment Requests (Date)

    (a) Definitions. As used in this clause--
    (1) Contract financing payment has the meaning given in FAR 
32.001.
    (2) Designated agency office means the office designated by the 
purchase order, agreement, or contract to first receive and review 
invoices. This office can be contractually designated as the 
receiving entity. This office may be different from the office 
issuing the payment.
    (3) Electronic form means an automated system transmitting 
information electronically according to the accepted electronic data 
transmission methods and formats identified in paragraph (c) of this 
clause. Facsimile, email, and scanned documents are not acceptable 
electronic forms for submission of payment requests.
    (4) Invoice payment has the meaning given in FAR 32.001.
    (5) Payment request means any request for contract financing 
payment or invoice payment submitted by the contractor under this 
contract.
    (b) Electronic payment requests. Except as provided in paragraph 
(e) of this clause, the contractor shall submit payment requests in 
electronic form. Purchases paid with a Government-wide commercial 
purchase card are considered to be an electronic transaction for 
purposes of this rule, and therefore no additional electronic 
invoice submission is required.
    (c) Data transmission. A contractor must ensure that the data 
transmission method and format are through one of the following:
    (1) VA's Electronic Invoice Presentment and Payment System at 
the current website address provided in the contract.
    (2) Any system that conforms to the X12 electronic data 
interchange (EDI) formats established by the Accredited Standards 
Center (ASC) and chartered by the American National Standards 
Institute (ANSI).
    (d) Invoice requirements. Invoices shall comply with FAR 32.905.
    (e) Exceptions. If, based on one of the circumstances below, the 
Contracting Officer directs that payment requests be made by mail, 
the contractor shall submit payment requests by mail through the 
United States Postal Service to the designated agency office. 
Submission of payment requests by mail may be required for--
    (1) Awards made to foreign vendors for work performed outside 
the United States;
    (2) Classified contracts or purchases when electronic submission 
and processing of payment requests could compromise the safeguarding 
of classified or privacy information;
    (3) Contracts awarded by Contracting Officers in the conduct of 
emergency operations, such as responses to national emergencies;
    (4) Solicitations or contracts in which the designated agency 
office is a VA entity other than the VA Financial Services Center in 
Austin, Texas; or
    (5) Solicitations or contracts in which the VA designated agency 
office does not have electronic invoicing capability as described 
above.


(End of clause)


Sec.  852.236-82  [Removed and reserved].


Sec.  852.236-83  [Removed and reserved].

0
35. Remove and reserve sections 852.236-82 and 852.236-83.

PART 870--SPECIAL PROCUREMENT CONTROLS

0
36. The authority citation for part 870 is revised to read as follows:

    Authority: 40 U.S.C. 121(c); 41 U.S.C. 1702; and 48 CFR 1.301-
1.304.


Sec.  870.112  [Removed]


Sec.  870.113  [Removed]

0
37. Remove sections 870. 112 and 870.113.

[FR Doc. 2018-04002 Filed 3-23-18; 8:45 am]
BILLING CODE 8320-01-P



                                                  12922                   Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules

                                                  request as meeting Federal requirements                   Dated: March 15, 2018.                              Acquisition Regulation to Adhere to
                                                  and does not impose additional                          Alexandra Dapolito Dunn,                              Federal Acquisition Regulation
                                                  requirements beyond those imposed by                    Regional Administrator, EPA Region 1.                 Principles (VAAR Case 2014–V004—
                                                  state law. For that reason, this proposed               [FR Doc. 2018–06005 Filed 3–23–18; 8:45 am]           parts 811, 832).’’ Copies of comments
                                                  action:                                                 BILLING CODE 6560–50–P
                                                                                                                                                                received will be available for public
                                                     • Is not a significant regulatory action                                                                   inspection in the Office of Regulation
                                                  subject to review by the Office of                                                                            Policy and Management, Room 1063B,
                                                  Management and Budget under                                                                                   between the hours of 8:00 a.m. and 4:30
                                                                                                          DEPARTMENT OF VETERANS                                p.m., Monday through Friday (except
                                                  Executive Orders 12866 (58 FR 51735,
                                                                                                          AFFAIRS                                               holidays). Please call (202) 461–4902 for
                                                  October 4, 1993) and 13563 (76 FR 3821,
                                                  January 21, 2011);                                      [8320–01]                                             an appointment. (This is not a toll-free
                                                     • does not impose an information                                                                           number.) In addition, during the
                                                  collection burden under the provisions                  48 CFR Parts 801, 811, 832, 852, and                  comment period, comments may be
                                                  of the Paperwork Reduction Act (44                      870                                                   viewed online through the Federal
                                                  U.S.C. 3501 et seq.);                                                                                         Docket Management System (FDMS) at
                                                                                                          RIN 2900–AP81                                         www.Regulations.gov.
                                                     • is certified as not having a
                                                  significant economic impact on a                        Revise and Streamline VA Acquisition                  FOR FURTHER INFORMATION CONTACT: Mr.
                                                  substantial number of small entities                    Regulation—Parts 811 and 832                          Ricky Clark, Senior Procurement
                                                  under the Regulatory Flexibility Act (5                                                                       Analyst, Procurement Policy and
                                                  U.S.C. 601 et seq.);                                    AGENCY:    Department of Veterans Affairs.            Warrant Management Services, 003A2A,
                                                     • does not contain any unfunded                      ACTION:   Proposed rule.                              425 I Street NW, Washington DC 20001,
                                                  mandate or significantly or uniquely                                                                          (202) 697–3565. (This is not a toll-free
                                                  affect small governments, as described                  SUMMARY:   The Department of Veterans                 telephone number.)
                                                  in the Unfunded Mandates Reform Act                     Affairs (VA) is proposing to amend and                SUPPLEMENTARY INFORMATION:
                                                  of 1995 (Public Law 104–4);                             update its VA Acquisition Regulation
                                                                                                          (VAAR) in phased increments to revise                 Background
                                                     • does not have Federalism
                                                  implications as specified in Executive                  or remove any policy superseded by                       This rulemaking is issued under the
                                                  Order 13132 (64 FR 43255, August 10,                    changes in the Federal Acquisition                    authority of the Office of Federal
                                                  1999);                                                  Regulation (FAR), to remove any                       Procurement Policy (OFPP) Act which
                                                     • is not an economically significant                 procedural guidance internal to VA into               provides the authority for an agency
                                                  regulatory action based on health or                    the VA Acquisition Manual (VAAM),                     head to issue agency acquisition
                                                  safety risks subject to Executive Order                 and to incorporate any new agency                     regulations that implement or
                                                  13045 (62 FR 19885, April 23, 1997);                    specific regulations or policies. These               supplement the FAR.
                                                                                                          changes seek to streamline and align the                 VA is proposing to revise the VAAR
                                                     • is not a significant regulatory action                                                                   to add new policy or regulatory
                                                  subject to Executive Order 13211 (66 FR                 VAAR with the FAR and remove
                                                                                                          outdated and duplicative requirements                 requirements and to remove any
                                                  28355, May 22, 2001);                                                                                         redundant guidance and guidance that
                                                                                                          and reduce burden on contractors. The
                                                     In addition, this rulemaking is not                                                                        is applicable only to VA’s internal
                                                                                                          VAAM incorporates portions of the
                                                  subject to requirements of section 12(d)                                                                      operating processes or procedures.
                                                                                                          removed VAAR as well as other internal
                                                  of the National Technology Transfer and                                                                       Codified acquisition regulations may be
                                                                                                          agency acquisition policy. VA will
                                                  Advancement Act of 1995 (15 U.S.C.                                                                            amended and revised only through
                                                                                                          rewrite certain parts of the VAAR and
                                                  272 note) because application of those                                                                        rulemaking. All amendments, revisions,
                                                                                                          VAAM, and as VAAR parts are
                                                  requirements would be inconsistent                                                                            and removals have been reviewed and
                                                                                                          rewritten, we’ll publish them in the
                                                  with the CAA. It also does not provide                                                                        concurred with by VA’s Integrated
                                                                                                          Federal Register. VA will combine
                                                  EPA with the discretionary authority to                                                                       Product Team of agency stakeholders.
                                                                                                          related topics, as appropriate. In
                                                  address, as appropriate,                                                                                         The VAAR uses the regulatory
                                                                                                          particular, this rulemaking revises
                                                  disproportionate human health or                                                                              structure and arrangement of the FAR
                                                                                                          VAAR Parts 811—Describing Agency
                                                  environmental effects, using practicable                                                                      and headings and subject areas are
                                                                                                          Needs and Part 832—Contract
                                                  and legally permissible methods, under                                                                        broken up consistent with the FAR
                                                                                                          Financing, as well as affected parts
                                                  Executive Order 12898 (59 FR 7629,                                                                            content. The VAAR is divided into
                                                                                                          801—Department of Veterans Affairs
                                                  February 16, 1994). And it does not                                                                           subchapters, parts (each of which covers
                                                                                                          Acquisition Regulation System, 852—
                                                  have Tribal implications as specified by                                                                      a separate aspect of acquisition),
                                                                                                          Solicitation Provisions and Contract
                                                  Executive Order 13175 (65 FR 67249,                                                                           subparts, sections, and subsections.
                                                                                                          Clauses, and 870—Special Procurement
                                                  November 9, 2000), because the EPA is                                                                            The Office of Federal Procurement
                                                                                                          Controls.
                                                  not proposing to approve the submitted                                                                        Policy Act, as codified in 41 U.S.C.
                                                  rule to apply in Indian country located                 DATES: Comments must be received on                   1707, provides the authority for the
                                                  in the State, and because the submitted                 or before May 25, 2018 to be considered               Federal Acquisition Regulation and for
                                                  rule will not impose substantial direct                 in the formulation of the final rule.                 the issuance of agency acquisition
                                                  costs on Tribal governments or preempt                  ADDRESSES: Written comments may be                    regulations consistent with the FAR.
                                                  Tribal law.                                             submitted through                                        When Federal agencies acquire
                                                                                                          www.Regulations.gov; by mail or hand-                 supplies and services using
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  List of Subjects in 40 CFR Parts 61 and                 delivery to Director, Regulation Policy               appropriated funds, the purchase is
                                                  63                                                      and Management (00REG), Department                    governed by the FAR, set forth at Title
                                                    Environmental protection,                             of Veterans Affairs, 810 Vermont                      48 Code of Federal Regulations (CFR),
                                                  Administrative practice and procedure,                  Avenue NW, Room 1063B, Washington,                    chapter 1, parts 1 through 53, and the
                                                  Air pollution control, Hazardous                        DC 20420; or by fax to (202) 273–9026.                agency regulations that implement and
                                                  substances, Incorporation by reference,                 Comments should indicate that they are                supplement the FAR. The VAAR is set
                                                  Intergovernmental relations, Reporting                  submitted in response to ‘‘RIN 2900–                  forth at Title 48 CFR, chapter 8, parts
                                                  and record keeping requirements.                        AP81—Revise and Streamline VA                         801 to 873.


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00059   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                                          Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules                                           12923

                                                  Discussion and Analysis                                 Budget Action dated March 2, 2015,                    VAAR Part 811—Describing Agency
                                                     The VA proposes to make the                          Information Collection Reference (ICR)                Needs
                                                  following changes to the VAAR in this                   201406–2900–017, which approved the
                                                                                                          removal of the information collection                    We propose to revise the Table of
                                                  phase of its revision and streamlining                                                                        Contents to reflect the revision of
                                                  initiative. For procedural guidance cited               and a reduction of the associated burden
                                                                                                          under OMB approval number 2900–                       subparts 811.1 and 811.2, and the
                                                  below that is proposed to be deleted                                                                          deletion of subparts 811.4, 811.5, and
                                                  from the VAAR, each section cited for                   0688. Therefore, it is proposed for
                                                                                                          removal from this table. Information                  811.6.
                                                  removal has been considered for                                                                                  We propose to revise the part 811
                                                                                                          collection is approved at the FAR level
                                                  inclusion in VA’s internal agency                                                                             authorities to add 41 U.S.C. 1702, which
                                                                                                          under FAR OMB approval number
                                                  operating procedures in accordance                                                                            addresses overall direction of
                                                                                                          9000–0138, making it unnecessary for a
                                                  with FAR 1.301(a)(2). Similarly,                                                                              procurement policy, acquisition
                                                                                                          separate information collection approval
                                                  delegations of authority that are                                                                             planning and management
                                                                                                          in the VAAR.
                                                  removed from the VAAR will be                              In section 801.106, OMB approval                   responsibilities of VA’s Chief
                                                  included in the VA Acquisition Manual                   under the Paperwork Reduction Act, we                 Acquisition Officer, and 41 U.S.C. 1303,
                                                  (VAAM) as internal agency guidance.                     propose to amend section 801.106 table                an updated positive law codification to
                                                  VAAR Part 801—Department of                             columns titled ‘‘48 CFR part or section               reflect additional authority of the VA as
                                                  Veterans Affairs Acquisition Regulation                 where identified and described,’’ and                 an executive agency to issue regulations
                                                  System                                                  ‘‘Current OMB control number.’’ We                    that are essential to implement
                                                                                                          propose to remove the reference to                    Governmentwide policies and
                                                     We propose to amend the authority                                                                          procedures in the agency, as well as to
                                                                                                          subsection 852.211–71, Special Notice,
                                                  for part 801 to remove the citation of 38                                                                     issue additional policies and procedures
                                                                                                          and discontinue the corresponding
                                                  U.S.C. 501, and to add 41 U.S.C. 1121,                                                                        required to satisfy the specific needs of
                                                                                                          OMB control number 2900–0588, as the
                                                  41 U.S.C. 1303, an updated positive law                                                                       the VA.
                                                                                                          provision conflicts with FAR 52.214–21.
                                                  codification of, to reflect additional                  It currently requires literature to be
                                                  authority of the VA as an executive                                                                              We propose to remove section
                                                                                                          provided after award and thus conflicts               811.001, Definitions, because the
                                                  agency to issue regulations that are                    with the FAR and the Government’s
                                                  essential to implement Governmentwide                                                                         coverage in FAR 11.104 provides
                                                                                                          procedures for evaluating relevant                    adequate coverage of what brand name
                                                  policies and procedures in the agency,                  materials during source selection and
                                                  as well as to issue additional policies                                                                       or equal purchase descriptions must
                                                                                                          prior to award decisions.                             include. The VAAR had merely
                                                  and procedures required to satisfy the                     In section 801.106, in reference to the
                                                  specific needs of the VA; and 41 U.S.C.                                                                       paraphrased the same information. In
                                                                                                          table described, we propose to remove                 accordance with FAR drafting standards
                                                  1702, which addresses overall direction                 the reference to subsection 852.211–73,
                                                  of procurement policy, acquisition                                                                            and the requirement in FAR 1.304(b)(1)
                                                                                                          Brand Name or Equal, and discontinue                  that agency acquisition regulations shall
                                                  planning and management                                 the corresponding OMB control number
                                                  responsibilities of VA’s Chief                                                                                not unnecessarily repeat, paraphrase, or
                                                                                                          2900–0585, as the topical area the                    otherwise restate material contained in
                                                  Acquisition Officer.                                    clause covers, ‘‘brand name or equal,’’
                                                     This proposed rule contains existing                                                                       the FAR, this section is therefore
                                                                                                          or ‘‘items peculiar to one                            proposed for removal.
                                                  information collection requirements.                    manufacturer,’’ has sufficient coverage
                                                  The proposed rule would result in                                                                                In subpart 811.1, Selecting and
                                                                                                          in FAR 11.105 and the associated
                                                  multiple actions affecting these                                                                              Developing Requirements Documents,
                                                                                                          provision in FAR 52.211–6, Brand Name
                                                  information collections, including                                                                            we propose to remove section 811.103,
                                                                                                          or Equal.
                                                  outright removal of the information                                                                           Market acceptance, and the underlying
                                                                                                             In section 801.106, in reference to the
                                                  collection and redesignating the                                                                              subsection 811.103–70, Technical
                                                                                                          table described, we propose to remove
                                                  information collection burden                                                                                 industry standards. We propose to
                                                                                                          the reference to section 852.236–82,
                                                  associated with several clauses or                                                                            revise the prescription to clause
                                                                                                          Payments under fixed-price
                                                  provisions by renumbering the clause or                                                                       852.211–72, Technical industry
                                                                                                          construction contracts (without NAS),
                                                  provision. We propose to revise certain                                                                       standards, for clarity and simplification
                                                                                                          and remove the reference to section
                                                  clause or provision numbers in VAAR                                                                           of the language, and to move the
                                                                                                          852.236–83, Payments under fixed-price
                                                  part 801 only when removing the actual                                                                        prescription of the clause to 811.204–70
                                                                                                          construction contracts (including NAS).
                                                  information collection and its associated                                                                     to comport with the FAR structure, as
                                                                                                          Both of these clauses, pertaining to
                                                  burden, or when redesignating and                                                                             technical industry standards are not
                                                                                                          ‘‘payments under fixed-price
                                                  renumbering the clause or provision                                                                           related to coverage in FAR 11.103, but
                                                                                                          construction,’’ have been renumbered to
                                                  under the associated Office of                                                                                would fall under FAR 11.204.
                                                                                                          reflect their prescription under Part 832.
                                                  Management and Budget (OMB)                             The associated OMB control number                        We propose to remove the section title
                                                  approval number.                                        2900–0422 will now reflect information                at 811.104, Use of Brand Name or Equal
                                                     In section 801.106, OMB approval                     collections under the new clause                      purchase descriptions, and subsection at
                                                  under the Paperwork Reduction Act, we                   numbers—852.232–70 and 852.232–71                     811.104–70, Brand name or equal
                                                  propose to amend section 801.106 table                  as described in further detail under the              purchase descriptions, because FAR
                                                  columns titled ‘‘48 CFR part or section                 Paperwork Reduction Act section of this               11.104, provides adequate coverage of
                                                  where identified and described,’’ and                                                                         what brand name or equal purchase
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                                                                          preamble, although these are not new
                                                  ‘‘Current OMB control number.’’ We                      collections.                                          descriptions must include.
                                                  propose to remove the reference to                                                                               We propose to remove subsections
                                                  section 832.006–4 and the associated                    Subchapter B—Competition and                          811.104–71, Purchase description
                                                  OMB control number 2900–0688. This                      Acquisition Planning                                  clauses, and 811.104–72, Limited
                                                  information collection burden under the                   We propose to revise the title of                   application of brand name or equal,
                                                  associated OMB control number was                       Subchapter B to conform to the title in               because the subject is adequately
                                                  previously removed via a published                      the Federal Acquisition Regulation, 48                covered in FAR clause 52.211–6, Brand
                                                  Notice of Office of Management and                      CFR, chapter 1, ‘‘Acquisition Planning.’’             name or equal.


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00060   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                  12924                   Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules

                                                     We propose to remove subsection                      and the deletion of subparts 832.5,                   and to reconfigure the paragraphs to
                                                  811.104–73, Bid samples, as coverage is                 832.8, and 832.11.                                    conform more closely to FAR
                                                  adequate in FAR 14.202–4, and clause                       We propose to revise the part 832                  prescription language for clauses and
                                                  52.214–20.                                              authorities to add 41 U.S.C. 1702, which              provisions. Also, the clauses were
                                                     We propose to remove subsection                      addresses overall direction of                        renumbered to reflect that they are
                                                  811.104–74, Bid evaluation and award,                   procurement policy, acquisition                       prescribed in part 832 and not 836 as
                                                  since it duplicates coverage in FAR                     planning and management                               they were previously numbered, and the
                                                  clause 52.211–6.                                        responsibilities of VA’s Chief                        clauses were retitled for clarification.
                                                     We propose to remove subsection                      Acquisition Officer; and 41 U.S.C. 1303,                 In subpart 832.2, Commercial Item
                                                  811.104–75, Procedure for negotiated                    to include an updated positive law                    Purchase Financing, we propose to
                                                  procurements, since there is no need to                 codification.                                         remove section 832.201, Statutory
                                                  have separate policy and procedures for                    We propose to add section 832.001,                 authority, and move internal procedural
                                                  negotiated and sealed bid solicitations.                Definitions. This section would add                   guidance not having a significant effect
                                                  FAR covers ‘‘brand name or equal’’                      three definitions of terms relating to                beyond the internal operating
                                                  without a distinction between sealed                    electronic invoicing. We propose to                   procedures of VA (see FAR 1.301(b))
                                                  bid and negotiated solicitations.                       amend subsection 832.006–1, General,                  and which will be moved to the VAAM.
                                                     We propose to remove 811.105, Items                  to spell out the title of Senior                      It contains a delegation of authority for
                                                  peculiar to one manufacturer, since the                 Procurement Executive (SPE) and to                    Contracting Officers to make
                                                  subject is adequately covered in FAR                    delete the last sentence as it provides               determinations regarding terms and
                                                  11.105.                                                 internal procedural guidance not having               conditions for payment for commercial
                                                     In subpart 811.1, section 811.107,                   a significant effect beyond the internal              items and whether they are appropriate,
                                                  Contract clauses, we propose to amend                   operating procedures of the VA (see                   customary, and in the best interest of
                                                  the number and title of the existing                    FAR 1.301(b)) and which will be moved                 the Government.
                                                  section to read as 811.107–70, Contract                 to the VAAM.                                             We propose to amend subsection
                                                  clause, to better reflect its placement in                 We propose to remove subsection                    832.202–1, Policy, to make the
                                                  accordance with FAR numbering                           832.006–2, Definitions, which only                    paragraph comport with the
                                                  conventions. It fits intelligibly as a                  included one definition for the Remedy                corresponding FAR coverage, to reflect
                                                  supplement to FAR 11.107, Solicitation                  Coordination Official (RCO). This                     that Heads of Contracting Activities
                                                  provision, but the VAAR is                              information would be added in                         (HCAs) shall report no later than
                                                  supplementing with a clause in this area                subsection 832.006–4 and would make                   December 31 of each calendar year, to
                                                  and not a provision, necessitating the                  the need for a separate definition                    the Senior Procurement Executive (SPE)
                                                  more accurate title. Subsection 811.107–                repeating the same thing unnecessary.                 and Deputy Senior Procurement
                                                  70 prescribes a new clause 852.211–70,                     We propose to remove subsection                    Executive (DSPE), on the number of
                                                  Equipment Operation and Maintenance                     832.006–3, Responsibilities, as it                    contracts for commercial items with
                                                  Manuals, which replaces the existing                    provides internal procedural guidance                 unusual contract financing, commercial
                                                  clause 852.211–70, Service data                         not having a significant effect beyond                interim or advance payments that were
                                                  manuals.                                                the internal operating procedures of VA               approved for the previous fiscal year (1
                                                     In subpart 811.2, Using and                          (see FAR 1.301(b)) and which will be                  October 20XX–30 September 20XX).
                                                  Maintaining Requirements Documents,                     moved to the VAAM.                                    This would stipulate what is to be
                                                  we propose to remove section 811.202,                      We propose to amend subsection                     included in the report, the amount of
                                                  Maintenance of standardization                          832.006–4, Procedures, to update the                  such unusual contracting financing,
                                                  documents, as it is procedural in nature                existing VA agency procedures and to                  commercial interim or advance
                                                  and will be moved to the VAAM.                          delete paragraphs (a) and (c) as internal             payments that were approved, and the
                                                     Under subpart 811.2, we propose to                   operating procedures of VA not having                 kind and amount of security obtained by
                                                  revise and renumber section 811.204,                    a significant effect beyond the internal              the contractor for the advance.
                                                  Contract clause, to subsection 811.204–                 operating procedures of the VA (see                      We propose to amend subsection
                                                  70, Contract clause, which contains text                FAR 1.301(b)) and which will be moved                 832.202–4, Security for Government
                                                  prescribing clause 852.211–72,                          to the VAAM. We propose to add new                    financing, to make the paragraphs
                                                  Technical industry standards. The                       paragraphs (b), (e), and (g) to implement             comport with the corresponding FAR
                                                  prescription for 852.211–72 was moved                   FAR required agency procedures which                  coverage, and to delete the mention of
                                                  from 811.103–70 to better comport with                  describes notifying contractors, the                  a Dun and Bradstreet report.
                                                  FAR structure numbering and                             contractor’s right to provide information                In subpart 832.4, Advance Payments
                                                  arrangement.                                            on its behalf concerning a finding of                 for Non-Commercial Items, we propose
                                                     We propose to remove subparts 811.4,                 fraud in payment requests, the time                   to amend 832.402, General, to provide
                                                  Delivery or Performance Schedules, and                  period to provide the information to the              updated and revised VA procedures on
                                                  811.5, Liquidated Damages, as the                       Government and that the Senior                        who in the VA is delegated authority to
                                                  policy is redundant to FAR guidance.                    Procurement Executive (SPE) will                      make the determination described at
                                                     We propose to remove subpart 811.6,                  provide a copy of each final                          FAR 32.402(c)(1)(iii) and to approve
                                                  Priorities and Allocations, as it provides              determination and supporting                          contract terms concerning advance
                                                  internal procedural guidance not having                 documentation to the contractor, the                  payments. This is delegated to the Head
                                                  a significant effect beyond the internal                RCO, the Contracting Officer, and the                 of the Contracting Activity (HCA).
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  operating procedures of the VA (see                     VA Office of Inspector General (OIG).                 Typically VA delegations are contained
                                                  FAR 1.301(b)) and which will be moved                      In subpart 832.1, Non-Commercial                   in the VAAM but here, where it may
                                                  to the VAAM.                                            Item Purchase Financing, we propose to                impact the use and approval of unique
                                                                                                          amend section 832.111, Contract clauses               financing arrangements that contractors
                                                  VAAR Part 832—Contract Financing                        for non-commercial purchases, to                      may need to be aware of, the delegation
                                                    We propose to revise the Table of                     renumber the section as subsection                    is being retained in the VAAR.
                                                  Contents to reflect the revision of                     832.111–70, retitle it as ‘‘VA contract                  We propose to amend section
                                                  subparts 832.1, 832.2, 832.9 and 832.70,                clauses for non-commercial purchases,’’               832.404, Exclusions, to renumber the


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00061   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                                          Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules                                             12925

                                                  paragraphs so it better comports with                   the other relevant definitions have been              conform to the standards reflected in the
                                                  the FAR coverage and to clarify                         moved to section 832.001, Definitions,                clause. It also requires the contractor to
                                                  language and the citation of the                        which covers the entire part. We                      submit proof of conformance to the
                                                  authorities listed. We include                          propose to revise the title to reflect                standard, how to obtain the standards
                                                  information regarding the applicability                 ‘‘Electronic payment requests,’’ and to               and requires the offeror to contact the
                                                  of 31 U.S.C. 3324(d)(2), which allows                   reflect text now in section 832.7002.                 Contracting Officer if a response is not
                                                  VA to issue advance payment for                            We propose to remove section                       received within two weeks of the
                                                  subscriptions or other charges for                      832.7002, Electronic payment requests,                offeror’s request.
                                                  newspapers, magazines, periodicals,                     as the content has been moved to                         We propose to remove subsections
                                                  and other publications for official use.                832.7001.                                             852.211–73, Brand Name or Equal;
                                                  In addition, the statutory authority is                    We propose to amend subsection                     852.211–74, Liquidated Damages; and
                                                  included in section 832.404 for 31                      832.7002–1, Data transmission, to                     852.211–75, Product Specifications, as
                                                  U.S.C. 1535, and permits the VA to                      renumber and redesignate it as                        they are all redundant to guidance
                                                  issue advance payment for services and                  subsection 832.7001–1; to remove the                  contained in the FAR.
                                                  supplies obtained from another                          website address from paragraph (a); to                   Also in part 852, we propose to add
                                                  Government agency. Further, language                    require the address to be provided in the             clause 852.232–70, Payments under
                                                  is added that includes that as permitted                contract; and to delete from paragraph                fixed-price construction contracts
                                                  by 5 U.S.C. 4109, VA is permitted to                    (b) a website which may in time become                (without NAS–CPM). This clause was
                                                  issue advance payment for all or any                    obsolete.                                             formerly 852.236–82, Payments under
                                                  part of the necessary expenses for                         We propose to amend subsection                     fixed-price construction contracts
                                                  training Government employees,                          832.7002–2, Contract clause, to                       (without NAS). This clause is revised to
                                                  including obtaining professional                        renumber and redesignate it as                        renumber it to 852.232–70 to reflect its
                                                  credentials under 5 U.S.C. 5757, in                     subsection 832.7001–2. We also propose                prescription under part 832, and to
                                                  Government or non-Government                            to add a stipulation to the prescription              revise the title of the ‘‘NAS’’ to ‘‘NAS–
                                                  facilities, including the purchase or                   that the clause does not apply to                     CPM,’’ to clarify the list of conditions in
                                                  rental of books, materials, and supplies                contracts paid with the                               paragraph (c) for allowing progress
                                                  or services directly related to the                     Governmentwide commercial purchase                    payments for stored supplies and
                                                  training of a Government employee.                      card.                                                 equipment, and to add a new paragraph
                                                     We propose to remove subparts 832.5,                                                                       (f) requiring notice to the contractor if
                                                                                                          VAAR Part 852—Solicitation Provisions
                                                  Progress Payments Based on Costs and                                                                          retainage is to be made on a progress
                                                                                                          and Contract Clauses
                                                  832.8, Assignment of Claims, as both                                                                          payment.
                                                  contain internal procedural guidance                      In part 852, we propose to amend the                   We propose to add clause 852.232–71,
                                                  not having a significant effect beyond                  authority by adding 41 U.S.C. 1303 to                 Payments under fixed-price
                                                  the internal operating procedures of VA                 include an updated positive law                       construction contracts (including NAS–
                                                  (see FAR 1.301(b)) and which will be                    codification, to reflect additional                   CPM). This clause was formerly
                                                  moved to the VAAM.                                      authority of the VA as an executive                   852.236–83, Payments under fixed-price
                                                     In subpart 832.9, Prompt Payment, we                 agency to issue regulations that are                  construction contracts (including NAS).
                                                  propose to revise section 832.904,                      essential to implement Governmentwide                 This clause is revised to renumber it as
                                                  Determining payment due dates, to                       policies and procedures in the agency,                852.232–71 to agree with its
                                                  remove the text, but retain the title in                as well as to issue additional policies               prescription in Part 832, to revise the
                                                  the VAAR as it is related to a new                      and procedures required to satisfy the                title of the ‘‘NAS’’ to ‘‘NAS–CPM,’’ and
                                                  proposed subsection that will fall                      specific needs of the VA.                             to clarify the list of conditions in
                                                  underneath it. The procedures in the                      We propose to amend section                         paragraph (c) for allowing progress
                                                  text will be moved to the VAAM as                       852.211–70, Service data manuals, and                 payments for stored supplies and
                                                  internal operational procedures of the                  to revise the title to read, ‘‘Equipment              equipment, and to add a new paragraph
                                                  VA.                                                     Operation and Maintenance Manuals.’’                  (f) requiring notice to the contractor if
                                                     We propose to add subsection                         This requires Contracting Officers to                 retainage is to be made on a progress
                                                  832.904–70 to implement OMB                             insert this revised clause in solicitations           payment.
                                                  Memorandum M–11–32, dated                               for technical medical equipment and                      We propose to amend clause 852.232–
                                                  September 14, 2011, and to encourage                    devices, and/or other technical and                   72, Electronic Submission of Payment
                                                  making payments to small business                       mechanical equipment where the                        Requests, to revise the definition of
                                                  contractors within 15 days of receipt of                requiring activity determines manuals                 ‘‘designated agency office,’’ and to
                                                  invoice.                                                are a necessary requirement for                       delete a website address and system
                                                     We propose to remove subpart 832.11,                 operation and maintenance of the                      specifications.
                                                  Electronic Funds Transfer, and section                  equipment. It removes the prior                          We propose to delete the clauses
                                                  832.1106, EFT mechanisms, as they                       extensive detailed list of specific                   852.236–82, Payments Under Fixed-
                                                  contain internal procedural guidance                    information that would need to be                     Price Construction Contracts (without
                                                  not having a significant effect beyond                  developed and instead relies on existing              NAS), and 852.236–83, Payments Under
                                                  the internal operating procedures of VA                 commercial industry practices to                      Fixed-Price Construction Contracts
                                                  (see FAR 1.301(b)) and which will be                    provide already developed commercial                  (including NAS) as they have been
                                                  moved to the VAAM.                                      manuals.
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                                                                                                                                renumbered to comport with FAR
                                                     In subpart 832.70, Electronic                          We propose to remove subsection                     arrangements and more properly belong
                                                  Invoicing Requirements, we propose to                   852.211–71, Special Notice, as it is                  in VAAR part 832 as noted above.
                                                  amend section 832.7000, General, to                     redundant to guidance contained in the
                                                  reflect that the subpart contains policy                FAR.                                                  VAAR Part 870—Special Procurement
                                                  requirements rather than procedures.                      We propose to amend subsection                      Controls
                                                     We propose to remove section                         852.211–72, Technical industry                          We propose to remove section
                                                  832.7001, Definitions, since two of the                 standards, to more clearly set forth the              870.112, Telecommunications
                                                  definitions are provided in the FAR and                 requirements that the contractor shall                equipment, as it contains the


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00062   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                  12926                   Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules

                                                  prescription and requirement for review                 governments or communities; (2) Create                existing information collection approval
                                                  of descriptive literature required by the               a serious inconsistency or otherwise                  numbers associated with this proposed
                                                  clause 852.211–71, Special notice,                      interfere with an action taken or                     rule. Although this action contains
                                                  which is proposed for removal as noted                  planned by another agency; (3)                        provisions constituting collections of
                                                  elsewhere in the preamble.                              Materially alter the budgetary impact of              information at 48 CFR 852.236–82 and
                                                    We propose to remove section                          entitlements, grants, user fees, or loan              852.236–83, under the provisions of the
                                                  870.113, Paid use of conference                         programs or the rights and obligations of             Paperwork Reduction Act (44 U.S.C.
                                                  facilities, as it contains internal                     recipients thereof; or (4) Raise novel                3501–3521), no new proposed
                                                  procedural guidance not having a                        legal or policy issues arising out of legal           collections of information are associated
                                                  significant effect beyond the internal                  mandates, the President’s priorities, or              with these clauses. The information
                                                  operating procedures of VA (see FAR                     the principles set forth in this Executive            collection requirements for 48 CFR
                                                  1.301(b)) and which will be moved to                    order.’’                                              852.236–82 and 852.236–83 are
                                                  the VAAM.                                                  VA has examined the economic,                      currently approved by the Office of
                                                                                                          interagency, budgetary, legal, and policy             Management and Budget (OMB) and
                                                  Effect of Rulemaking
                                                                                                          implications of this regulatory action,               have been assigned OMB control
                                                    Title 48, Federal Acquisition                         and it has been determined this rule is               number 2900–0422. However, this
                                                  Regulations System, Chapter 8,                          not a significant regulatory action under             information collection has been
                                                  Department of Veterans Affairs, of the                  E.O. 12866.                                           submitted to OMB to revise the title and
                                                  Code of Federal Regulations, as                            VA’s impact analysis can be found as               to redesignate and renumber the two
                                                  proposed to be revised by this                          a supporting document at http://                      clauses currently numbered as sections
                                                  rulemaking, would represent VA’s                        www.regulations.gov, usually within 48                852.236–82, Payments Under Fixed-
                                                  implementation of its legal authority                   hours after the rulemaking document is                Price Construction Contracts (without
                                                  and publication of the Department of                    published. Additionally, a copy of the                NAS), and 852.236–83, Payments Under
                                                  Veterans Affairs Acquisition Regulation                 rulemaking and its impact analysis are                Fixed-Price Construction Contracts
                                                  (VAAR) for the cited applicable parts.                  available on VA’s website at http://                  (including NAS). Accordingly, if
                                                  Other than future amendments to this                    www.va.gov/orpm by following the link                 approved, they would reflect the new
                                                  rule or governing statutes for the cited                for VA Regulations Published from FY                  designation and revised titles as set
                                                  applicable parts, or as otherwise                       2004 Through Fiscal Year to Date. This                forth in the preamble and the
                                                  authorized by approved deviations or                    proposed rule is expected to be an E.O.               amendatory language of this proposed
                                                  waivers in accordance with Federal                      13771 deregulatory action. Details on                 rule to read: 852.232–70, Payments
                                                  Acquisition Regulation (FAR) subpart                    the estimated cost savings of this                    Under Fixed-Price Construction
                                                  1.4, Deviations from the FAR, and as                    proposed rule can be found in the rule’s              Contracts (without NAS–CPM), and
                                                  implemented by VAAR subpart 801.4,                      economic analysis.
                                                  Deviations from the FAR or VAAR, no                                                                           852.232–71, Payments Under Fixed-
                                                  contrary guidance or procedures would                   Paperwork Reduction Act (PRA)                         Price Construction Contracts (including
                                                  be authorized. All existing or                             This proposed rule impacts seven                   NAS–CPM), respectively, under the
                                                  subsequent VA guidance would be read                    existing information collection                       associated OMB control number 2900–
                                                  to conform with the rulemaking if                       requirements associated with six Office               0422. The references to the old
                                                  possible or, if not possible, such                      of Management and Budget (OMB)                        numbers—852.236–82 and 852.236–83,
                                                  guidance would be superseded by this                    control number approvals. The                         would accordingly be removed. There is
                                                  rulemaking as pertains to the cited                     proposed actions in this rule result in               no change in the information collection
                                                  applicable VAAR parts.                                  multiple actions affecting some of these              burden that is associated with this
                                                                                                          information collections, such as: the                 proposed request. As required by the
                                                  Executive Order 12866, 13563 and                                                                              Paperwork Reduction Act of 1995 (at 44
                                                                                                          proposed outright removal of the
                                                  13771                                                                                                         U.S.C. 3507(d)), VA has submitted these
                                                                                                          information collection; no change in
                                                     Executive Orders (E.O.) 12866 and                    information collection burdens although               information collection amendments to
                                                  13563 direct agencies to assess all costs               titles and numbers may be changed or                  OMB for its review. Notice of OMB
                                                  and benefits of available regulatory                    the clauses moved to other parts of the               approval for this information collection
                                                  alternatives and, if regulation is                      VAAR; a reduction in existing                         will be published in a future Federal
                                                  necessary, to select regulatory                         information collection burdens; and the               Register document.
                                                  approaches that maximize net benefits                   proposed redesignation of the existing                   This proposed rule would impose the
                                                  (including potential economic,                          approved OMB collection numbers and                   following amended information
                                                  environmental, public health and safety                 the associated burden as a result of two              collection requirements to one of the six
                                                  effects, distributive impacts, and                      clauses we propose to both retitle and                existing information collection approval
                                                  equity). E.O. 13563 emphasizes the                      renumber.                                             numbers associated with this proposed
                                                  importance of quantifying both costs                       The Paperwork Reduction Act of 1995                rule. Although this action contains
                                                  and benefits of reducing costs, of                      (at 44 U.S.C. 3507) requires that VA                  provisions constituting collections of
                                                  harmonizing rules, and of promoting                     consider the impact of paperwork and                  information at 48 CFR 852.211–70,
                                                  flexibility. E.O. 12866, Regulatory                     other information collection burdens                  Service data manuals, under the
                                                  Planning and Review defines                             imposed on the public. Under 44 U.S.C.                provisions of the Paperwork Reduction
                                                  ‘‘significant regulatory action’’ to mean               3507(a), an agency may not collect or                 Act (44 U.S.C. 3501–3521), no new
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  any regulatory action that is likely to                 sponsor the collection of information,                proposed information collection is
                                                  result in a rule that may: ‘‘(1) Have an                nor may it impose an information                      associated with this clause. The
                                                  annual effect on the economy of $100                    collection requirement unless it                      information collection requirement for
                                                  million or more or adversely affect in a                displays a currently valid OMB control                48 CFR 852.211–70 is currently
                                                  material way the economy, a sector of                   number. See also 5 CFR 1320.8(b)(3)(vi).              approved by OMB and has been
                                                  the economy, productivity, competition,                    This proposed rule would impose the                assigned OMB control number 2900–
                                                  jobs, the environment, public health or                 following amended information                         0587. However, this information
                                                  safety, or State, local, or tribal                      collection requirements to two of the six             collection has been submitted to OMB


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00063   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                                          Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules                                              12927

                                                  to revise the title from ‘‘Service Data                 collection of information at 48 CFR                   issuing any rule that may result in the
                                                  Manuals,’’ to read, ‘‘Equipment                         852.211–72, Technical industry                        expenditure by State, local, and tribal
                                                  Operation and Maintenance Manuals.’’                    standards, and 48 CFR 832.202–4,                      Governments, in the aggregate, or by the
                                                  We propose to reflect the revised title as              Security for Government financing,                    private sector, of $100 million or more
                                                  set forth in the preamble and the                       which remain unchanged. Under the                     (adjusted annually for inflation) in any
                                                  amendatory language of this proposed                    provisions of the Paperwork Reduction                 one year. This proposed rule would
                                                  rule for this clause to read: 852.211–70,               Act of 1995 (44 U.S.C. 3501–3521), no                 have no such effect on State, local, and
                                                  Equipment Operation and Maintenance                     new or proposed revised collection of                 tribal Governments or on the private
                                                  Manuals, under the associated OMB                       information is associated with these                  sector.
                                                  control number 2900–0587. We propose                    provisions as a part of this proposed
                                                                                                                                                                List of Subjects
                                                  to remove the reference in the existing                 rule. The information collection
                                                  OMB control number to the old title.                    requirements for 48 CFR 852.211–72                    48 CFR Part 801
                                                  There is also a reduction in the                        and 48 CFR 832.202–4 are currently                      Administrative practice and
                                                  information collection burden that is                   approved by the OMB and have been                     procedure, Government procurement,
                                                  associated with this proposed request.                  assigned OMB control numbers 2900–                    Reporting and recordkeeping
                                                  The previously approved estimated                       0586 and 2900–0688, respectively. The                 requirements.
                                                  annual hourly burden is 621 hours. As                   burden of these information collections
                                                  a result of revising the clause and                     remains unchanged. In accordance with                 48 CFR Part 811and 832
                                                  removing the requirement to develop                     the Paperwork Reduction Act of 1995                     Government procurement.
                                                  Government-specified service manuals,                   (44 U.S.C. 3501–3521), the OMB has
                                                  the VA has eliminated an unnecessary                    approved the reporting or recordkeeping               48 CFR Part 852
                                                  burden on the public by making use of                   provisions that are included in the                     Government procurement, Reporting
                                                  commercial operation and maintenance                    clause and the text under section                     and recordkeeping requirements.
                                                  manuals just like the general public and                832.202–4 cited above and has given the
                                                                                                                                                                48 CFR Part 870
                                                  established commercial practices,                       VA the following approval numbers:
                                                  thereby reducing by half the estimated                  OMB 2900–0586 and OMB 2900–0688,                        Asbestos, Frozen foods, Government
                                                  annual hourly burden which is now                       respectively.                                         procurement, Telecommunications.
                                                  estimated at 311 hours, a reduction of                                                                        Signing Authority
                                                                                                          Regulatory Flexibility Act
                                                  310 annual hours. As required by the
                                                  Paperwork Reduction Act of 1995 (at 44                    This proposed rule would not have a                   The Secretary of Veterans Affairs, or
                                                  U.S.C. 3507(d)), VA has submitted this                  significant economic impact on a                      designee, approved this document and
                                                  information collection amendment to                     substantial number of small entities as               authorized the undersigned to sign and
                                                  OMB for its review. Notice of OMB                       they are defined in the Regulatory                    submit the document to the Office of the
                                                  approval for this information collection                Flexibility Act, 5 U.S.C. 601–612. The                Federal Register for publication
                                                  will be published in a future Federal                   overall impact of the proposed rule                   electronically as an official document of
                                                  Register document.                                      would be of benefit to small businesses               the Department of Veterans Affairs. Gina
                                                     This proposed rule would remove two                  owned by Veterans or service-disabled                 S. Farrisee, Deputy Chief of Staff,
                                                  of the six existing information collection              Veterans as the VAAR is being updated                 Department of Veterans Affairs,
                                                  requirements associated with this action                to remove extraneous procedural                       approved this document on August 7,
                                                  at 48 CFR 852.211–71, Special Notice,                   information that applies only to VA’s                 2017, for publication.
                                                  and 48 CFR 852.211–73, Brand Name or                    internal operating procedures. VA is                    Dated: February 22, 2018.
                                                  Equal. Under the provisions of the                      merely adding existing and current                    Consuela Benjamin,
                                                  Paperwork Reduction Act (44 U.S.C.                      regulatory requirements to the VAAR                   Office of Regulation Policy & Management,
                                                  3501–3521), it discontinues the                         and removing any guidance that is                     Office of the Secretary, Department of
                                                  associated corresponding approved                       applicable only to VA’s internal                      Veterans Affairs.
                                                  OMB control numbers, 2900–0588 and                      operation processes or procedures. VA                   For the reasons set out in the
                                                  2900–0585, respectively. As a result of                 estimates no cost impact to individual                preamble, VA proposes to amend 48
                                                  this proposed rule, there is a removal in               business would result from these rule                 CFR, chapter 8, parts 801, 811, 832, 852,
                                                  the information collection burden that is               updates. This rulemaking does not                     and 870 as follows:
                                                  associated with the removal of these two                change VA’s policy regarding small
                                                  information collection requirements.                    businesses, does not have an economic                 PART 801—DEPARTMENT OF
                                                  For 48 CFR 852.211–71, Special Notice,                  impact to individual businesses, and                  VETERANS AFFAIRS ACQUISITION
                                                  and its corresponding OMB control                       there are no increased or decreased                   REGULATION SYSTEM
                                                  number 2900–0588, this results in a                     costs to small business entities. On this
                                                  removal of 875 estimated annual burden                                                                        ■  1. The authority citation for part 801
                                                                                                          basis, the proposed rule would not have
                                                  hours. For 48 CFR 852.211–73, Brand                                                                           is revised to read as follows:
                                                                                                          an economic impact on a substantial
                                                  Name or Equal, and its corresponding                    number of small entities as they are                    Authority: 40 U.S.C. 121(c); 41 U.S.C.
                                                  OMB control number 2900–0585, this                      defined in the Regulatory Flexibility                 1121; 41 U.S.C. 1303; 41 U.S.C. 1702; and 48
                                                  results in a removal of 1,125 estimated                                                                       CFR 1.301–1.304.
                                                                                                          Act, 5 U.S.C. 601–612. Therefore, under
                                                  annual burden hours. As required by the                 5 U.S.C. 605(b), this regulatory action is            Subpart 801.1—Purpose, Authority,
                                                  Paperwork Reduction Act of 1995 (at 44
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                                                                          exempt from the initial and final                     Issuance 801.106 [Amended]
                                                  U.S.C. 3507(d)), VA has submitted this                  regulatory flexibility analysis
                                                  information collection amendment to                     requirements of sections 603 and 604.                 ■  2. Amend the section 801.106 table
                                                  OMB for its review. Notice of OMB                                                                             columns titled ‘‘48 CFR part or section
                                                  approval for this information collection                Unfunded Mandates                                     where identified and described’’ and
                                                  will be published in a future Federal                     The Unfunded Mandates Reform Act                    ‘‘Current OMB control number’’ to—
                                                  Register document.                                      of 1995 requires, at 2 U.S.C. 1532, that              ■ a. Remove the reference to section
                                                     This proposed rule also contains two                 agencies prepare an assessment of                     832.006–4 and OMB Control Number
                                                  other provisions constituting a                         anticipated costs and benefits before                 2900–0668.


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00064   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                  12928                   Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules

                                                  ■ b. Remove the reference to section                    Subpart 811.5— Removed and                            carry out the responsibilities of the
                                                  852.211–71 and OMB Control Number                       reserved]                                             Secretary or designee in FAR 32.006–
                                                  2900–0588.                                                                                                    4(b). To determine whether substantial
                                                                                                          ■ 9. Subpart 811.5 is removed and                     evidence exists that the request for
                                                  ■ c. Remove the reference to section
                                                                                                          reserved.                                             payment under a contract is based on
                                                  852.211–73 and OMB Control Number
                                                  2900–0585.                                              Subpart 811.6—[Removed and                            fraud.
                                                  ■ d. Remove ‘‘852.236–82 through’’;.                    reserved]                                                (e) The RCO shall carry out the
                                                  ■ e. Add the reference to sections                                                                            responsibilities of the agency head in
                                                                                                          ■ 10. Subpart 811.6 is removed and
                                                  852.232–70 and 852.232–71 and OMB                                                                             FAR 32.006–4(e) to notify the contractor
                                                                                                          reserved.
                                                  control number 2900–0422 on the same                                                                          of the reasons for the recommended
                                                  line.                                                   PART 832—CONTRACT FINANCING                           action and of its right to submit
                                                  *     *    *     *     *                                                                                      information within a reasonable period
                                                                                                          ■  11. The authority citation for part 832            of time in response to the proposed
                                                  SUBCHAPTER B—[Amended]                                  is revised to read as follows:                        action under FAR 32.006.
                                                  ■ 3. The title of subchapter B is revised                 Authority: 40 U.S.C. 121(c); 41 U.S.C.                 (1) The notice of proposed action will
                                                  to read as follows:                                     1303; 41 U.S.C. 1702; and 48 CFR 1.301–               be sent to the last known address of the
                                                                                                          1.304.
                                                  SUBCHAPTER B—ACQUISITION PLANNING                                                                             contractor, the contractor’s counsel, or
                                                                                                          ■ 12. Section 832.001 is added to read                agent for service of process, by certified
                                                  PART 811—DESCRIBING AGENCY                              as follows:                                           mail, return receipt requested, or any
                                                  NEEDS                                                                                                         other method that provides signed
                                                                                                          § 832.001    Definitions.
                                                                                                                                                                evidence of receipt. In the case of a
                                                  ■  4. The authority citation for part 811                  As used in this subpart:
                                                                                                                                                                business, the notice of proposed action
                                                  is revised to read as follows:                             (a) Designated agency office means
                                                                                                                                                                may be sent to any partner, principal,
                                                    Authority: 40 U.S.C. 121(c); 41 U.S.C.                the office designated by the purchase
                                                                                                          order, agreement, or contract to first                officer, director, owner or co-owner, or
                                                  1303; 41 U.S.C. 1702; and 48 CFR 1.301–                                                                       joint venture. The contractor will be
                                                  1.304.                                                  receive and review invoices. This office
                                                                                                          can be contractually designated as the                afforded an opportunity to appear before
                                                  § 811.001   [Removed]                                   receiving entity. This office may be                  the RCO to present information or
                                                                                                          different from the office issuing the                 argument in person or through a
                                                  ■ 5. Section 811.001 is removed.
                                                                                                          payment.                                              representative and may supplement the
                                                  ■ 6. Revise subpart 811.1 to read as                                                                          oral presentation with written
                                                  follows:                                                   (b) Electronic form means an
                                                                                                          automated system transmitting                         information and argument.
                                                  Subpart 811.1—Selecting and                             information electronically according to                  (2) The contractor may supplement
                                                  Developing Requirements Documents                       the accepted electronic data                          the oral presentation with written
                                                                                                          transmission methods identified in                    information and argument. The
                                                  § 811.107–70     Contract clause.                       832.7002–1. Facsimile, email, and                     proceedings will be conducted in an
                                                    The Contracting Officer shall insert                  scanned documents are not acceptable                  informal manner and without the
                                                  the clause at 852.211–70, Equipment                     electronic forms for submission of                    requirement for a transcript. If the RCO
                                                  Operation and Maintenance Manuals, in                   payment requests.                                     does not receive a reply from the
                                                  solicitations and contracts for technical                  (c) Payment request means any                      contractor within 30 calendar days, the
                                                  medical, and other technical and                        request for contract financing payment                RCO will base his or her
                                                  mechanical equipment and devices                        or invoice payment submitted by a                     recommendations on the information
                                                  where the requiring activity determines                 contractor under a contract.                          available. Any recommendation of the
                                                  manuals are a necessary requirement for                 ■ 13. Revise section 832.006–1 to read
                                                                                                                                                                RCO under FAR 31.006–4(a) and
                                                  operation and maintenance of the                        as follows:                                           paragraph (b) of this section, must
                                                  equipment.                                              § 832.006–1       General.                            address the results of this notification
                                                  ■ 7. Revise subpart 811.2 to read as                      (b) The Senior Procurement Executive                and the information, if any, provided by
                                                  follows:                                                (SPE) is authorized to make                           the contractor. After reviewing all the
                                                                                                          determinations that there is substantial              information, the RCO shall make a
                                                  Subpart 811.2—Using and Maintaining                                                                           recommendation to the SPE whether or
                                                                                                          evidence that contractors’ requests for
                                                  Requirements Documents                                                                                        not substantial evidence of fraud exists.
                                                                                                          advance, partial, or progress payments
                                                  § 811.204–70     Contract clause.                       are based on fraud and may direct that                   (g) In addition to following the
                                                                                                          further payments to the contractors be                procedures in FAR 32.006–4, the SPE
                                                     The Contracting Officer shall insert
                                                                                                          reduced or suspended, as provided in                  shall provide a copy of each final
                                                  the clause at 852.211–72, Technical
                                                                                                          FAR 32.006.                                           determination and the supporting
                                                  industry Standards, in solicitations and
                                                  contracts requiring conformance to                                                                            documentation to the contractor, the
                                                                                                          § 832.006–2       [Removed].
                                                  technical industry standards, federal                                                                         RCO, the Contracting Officer, and the
                                                  specifications, standards and                           § 832.006–3       [Removed].                          OIG. The Contracting Officer will place
                                                                                                                                                                a copy of the determination and the
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  commercial item descriptions unless                     ■ 14. Remove sections 832.006–2 and
                                                  comparable coverage is included in the                  832.006–3.                                            supporting documentation in the
                                                  item specification.                                     ■ 15. Section 832.006–4 is revised to                 contract file.
                                                                                                          read as follows:
                                                  Subpart 811.4—[Removed and                                                                                    Subpart 832.1—Non-Commercial Item
                                                  reserved].                                              § 832.006–4       Procedures.                         Purchase Financing
                                                                                                            (b) The Remedy Coordination Official
                                                  ■ 8. Subpart 811.4 is removed and                       (RCO) for VA is the Deputy Senior                     ■ 16. Section 832.111 is revised to read
                                                  reserved.                                               Procurement Executive (DSPE) and shall                as follows:


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00065   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                                             Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules                                              12929

                                                  § 832.111–70 VA contract clauses for non-                sheets and income statements for the                  U.S.C. 3324(a). The term ‘‘other
                                                  commercial purchases.                                    two preceding fiscal years. The                       publications’’ includes any publication
                                                    (a)(1) Insert the clause at 852.232–70,                statements should be prepared in                      printed, microfilmed, photocopied or
                                                  Payments under fixed-price                               accordance with generally accepted                    magnetically or otherwise recorded for
                                                  construction contracts (without NAS–                     accounting principles and must be                     auditory or visual use.
                                                  CPM) in solicitations and contracts that                 audited and certified by an independent                  (2) As permitted by 31 U.S.C. 1535,
                                                  contain the FAR clause at 52.232–5,                      public accountant or an appropriate                   VA allows advance payment for services
                                                  Payments Under Fixed-Price                               officer of the firm;                                  and supplies obtained from another
                                                  Construction Contracts, and if the                          (ii) A cash flow forecast for the                  Government agency.
                                                  solicitation or contract does not require                remainder of the contract term showing                   (3) As permitted by 5 U.S.C. 4109, VA
                                                  use of the ‘‘Network Analysis System—                    the planned origin and use of cash                    allows advance payment for all or any
                                                  Critical Path Method (NAS–CPM).’’                        within the firm or branch performing                  part of the necessary expenses for
                                                    (2) If the solicitation or contract                    the contract;                                         training Government employees,
                                                  includes guarantee period services, the                     (iii) Information on financing                     including obtaining professional
                                                  Contracting Officer shall use the clause                 arrangements disclosing the availability              credentials under 5 U.S.C. 5757, in
                                                  with its Alternate I.                                    of cash to finance contract performance,              Government or non-Government
                                                    (b)(1) Insert the clause at 852.232–71,                the contractor’s exposure to financial                facilities, including the purchase or
                                                  Payments under fixed-price                               risk, and credit arrangements;                        rental of books, materials, and supplies
                                                  construction contracts (including NAS–                      (iv) A statement of the status of all              or services directly related to the
                                                  CPM), in solicitations and contracts that                State, local, and Federal tax accounts,               training of a Government employee.
                                                  contain the FAR clause at 52.232–5,                      including any special mandatory
                                                                                                                                                                 *      *     *    *     *
                                                  Payments Under Fixed-Price                               contributions;
                                                  Construction Contracts, and if the                          (v) A description and explanation of               Subpart 832.5—5 [Removed and
                                                  solicitation or contract requires use of                 the financial effects of any leases,                  reserved].
                                                  the ‘‘Network Analysis System—Critical                   deferred purchase arrangements, patent
                                                  Path Method (NAS–CPM).’’                                 or royalty arrangements, insurance,                   ■ 22. Subpart 832.5 is removed and
                                                    (2) If the solicitation or contract                    planned capital expenditures, pending                 reserved.
                                                  includes guarantee period services, the                  claims, contingent liabilities, and other
                                                  Contracting Officer shall use the clause                 financial aspects of the business; and                Subpart 832.8 [Removed and
                                                  with its Alternate I.                                       (vi) Any other financial information               reserved].
                                                                                                           deemed necessary.
                                                  Subpart 832.2—Commercial Item                                                                                  ■ 23. Subpart 832.8 is removed and
                                                  Purchase Financing                                       Subpart 832.4—Advance Payments for                    reserved.
                                                                                                           Non-Commercial Items
                                                  § 832.201   [Removed].                                                                                         Subpart 832.9—Prompt Payment
                                                  ■ 17. Section 832.201 is removed.                        ■ 20. Section 832.402 is revised to read
                                                                                                                                                                 § 832.904    [Redesignated as 832.904–70].
                                                  ■ 18. Section 832.202–1 is revised to                    as follows:
                                                  read as follows:                                                                                               ■ 24. Redesignate section 832.904 as
                                                                                                           § 832.402    General.                                 832.904–70 and revise newly
                                                  § 832.202–1      Policy.                                    (c)(1)(iii) The authority to make the              redesignated section 832.904–70 to read
                                                     (d) HCAs shall report, no later than                  determination required by FAR                         as follows:
                                                  December 31st of each calendar year, to                  32.402(c)(1)(iii) and to approve contract
                                                                                                           terms is delegated to the head of the                 § 832.904–70 Determining payment due
                                                  the Senior Procurement Executive (SPE)                                                                         dates for small businesses.
                                                  and the DSPE, on the number of                           contracting activity (HCA). The request
                                                  contracts for commercial items with                      for approval shall include the                          Pursuant to Office of Management and
                                                  unusual contract financing or with                       information required by FAR 32.409–1                  Budget Memorandum M–11–32, dated
                                                  commercial interim or advance                            and shall address the standards for                   September 14, 2011, Contracting
                                                  payments approved for the previous                       advance payment in FAR 32.402(c)(2).                  Officers shall, to the full extent
                                                  fiscal year. The report shall include the                HCAs shall report, no later than                      permitted by law, make payments to
                                                  contract number and amount, the                          December 31st of each calendar year, to               small business contractors as soon as
                                                  amount of the unusual contract                           the Senior Procurement Executive (SPE)                practicable, with the goal of making
                                                  financing or with commercial interim or                  and the DSPE, on number of contracts                  payments within 15 days of receipt of a
                                                  advance payments approved, and the                       for non-commercial items with advance                 proper invoice and confirmation that
                                                  kind and amount of security obtained                     payments approved in the previous                     the goods and services have been
                                                  for the advance.                                         fiscal year. The report shall include the             received and accepted by the Federal
                                                  ■ 19. Section 832.202–4 is revised to                    contract number and amount, the                       Government.
                                                  read as follows:                                         amount of the advance payment, and                    § 832.11    [Removed and reserved].
                                                                                                           the kind and amount of security
                                                  § 832.202–4      Security for Government                 obtained for the advance.                             ■ 25. Subpart 832.11 is removed and
                                                  financing.                                               ■ 21. Amend section 832.404 by                        reserved.
                                                     (a)(2) An offeror’s financial condition               revising paragraph (b) to read as follows:            ■ 26. Revise subpart 832.70 to read as
                                                  may be considered adequate security to                                                                         follows:
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  protect the Government’s interest when                   § 832.404    Exclusions.
                                                  the Government provides contract                         *     *    *     *     *                              Subpart 832.70—Electronic Invoicing
                                                  financing. In assessing the offeror’s                      (b)(1) As permitted by 31 U.S.C.                    Requirements
                                                  financial condition, the Contracting                     3324(d)(2), VA allows advance payment                 Sec
                                                  Officer may obtain, to the extent                        for subscriptions or other charges for                832.7000 General
                                                  required, the following information—                     newspapers, magazines, periodicals,                   832.7001 Electronic payment requests
                                                     (i) A current year interim balance                    and other publications for official use,              832.7001–1 Data transmission
                                                  sheet and income statement and balance                   notwithstanding the provisions of 31                  832.7001–2 Contract clause



                                             VerDate Sep<11>2014    18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00066   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                  12930                       Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules

                                                  § 832.7000       General.                                 PART 852—SOLICITATION                                 been tested in accordance with the standards
                                                                                                            PROVISIONS AND CONTRACT                               and meet the contract requirement. Proof
                                                    This subpart prescribes policy                                                                                may also be furnished by the organization
                                                  requirements for submitting and                           CLAUSES
                                                                                                                                                                  listed above certifying that the item(s)
                                                  processing payment requests in                            ■  27. The authority citation for part 852            furnished have been tested in accordance
                                                  electronic form.                                          is revised to read as follows:                        with and conform to the specified standards.
                                                                                                                                                                     (c) Offerors may obtain the standards cited
                                                  § 832.7001       Electronic payment requests.               Authority: 38 U.S.C. 8127–8128, and 8151–           in this provision by submitting a request,
                                                     (a) The contractor shall submit                        8153; 40 U.S.C. 121(c); 41 U.S.C. 1303; 41            including the solicitation number, title and
                                                                                                            U.S.C. 1702; and 48 CFR 1.301–1.304.                  number of the publication to:
                                                  payment requests in electronic form
                                                  unless directed by the Contracting                                                                              (Organization)ll (Mail or email address) l
                                                                                                            Subpart 852.2—Text of Provisions and                  l
                                                  Officer to submit payment requests by                     Clauses                                                  (d) The offeror shall contact the
                                                  mail. Purchases paid with a                                                                                     Contracting Officer if response is not
                                                  Government-wide commercial purchase                       ■ 28. Section 852.211–70 is revised to                received within two weeks of the request.
                                                  card are considered to be an electronic                   read as follows:
                                                  transaction for purposes of this rule, and                                                                      (End of clause)
                                                                                                            § 852.211–70 Equipment Operation and
                                                  therefore no additional electronic                        Maintenance Manuals.                                  § 852.211–73      [Removed and reserved].
                                                  invoice submission is required.
                                                                                                              As prescribed in 811.107–70, insert
                                                     (b) The Contracting Officer may direct                 the following clause:                                 § 852.211–74      [Removed and reserved].
                                                  the contractor to submit payment
                                                                                                            EQUIPMENT OPERATION AND                               § 852.211–75      [Removed and reserved].
                                                  requests by mail, through the United
                                                  States Postal Service, to the designated                  MAINTENANCE MANUALS (DATE)                            ■ 31. Remove and reserve sections
                                                  agency office for—                                           The contractor shall follow standard               852.211–73 through 852.211–75.
                                                                                                            commercial practices to furnish manual(s),            ■ 32. Add section 852.232–70 to read as
                                                     (1) Awards made to foreign vendors
                                                                                                            handbook(s) or brochure(s) containing                 follows:
                                                  for work performed outside the United                     operation, installation, and maintenance
                                                  States;                                                   instructions, including pictures or                   § 852.232–70 Payments under fixed-price
                                                     (2) Classified contracts or purchases                  illustrations, schematics, and complete               construction contracts (without NAS–CPM).
                                                  when electronic submission and                            repair/test guides, as necessary, for technical         As prescribed in 832.111–70, insert
                                                  processing of payment requests could                      medical equipment and devices, and/or other           the following clause in contracts that do
                                                  compromise the safeguarding of                            technical and mechanical equipment                    not contain a section entitled ‘‘Network
                                                  classified or privacy information;                        provided per CLIN(s) # (Contracting Officer
                                                                                                            insert CLIN information). The manuals,
                                                                                                                                                                  Analysis System—Critical Path Method
                                                     (3) Contracts awarded by Contracting                   handbooks or brochures shall be provided in           (without NAS–CPM)’’
                                                  Officers in the conduct of emergency                      hard copy, soft copy or with electronic access        Payments Under Fixed-Price
                                                  operations, such as responses to                          instructions, consistent with standard                Construction Contracts (Without NAS–
                                                  national emergencies;                                     industry practices for the equipment or
                                                                                                            device. Where applicable, the manuals,
                                                                                                                                                                  CPM) (Date)
                                                     (4) Solicitations or contracts in which
                                                  the designated agency office is a VA                      handbooks or brochures will include                     The clause FAR 52.232–5, Payments under
                                                  entity other than the VA Financial                        electrical data and connection diagrams for           Fixed-Price Construction Contracts, is
                                                                                                            all utilities. The documentation shall also           implemented as follows:
                                                  Services Center in Austin, Texas; or                      contain a complete list of all replaceable              (a) Retainage.
                                                     (5) Solicitations or contracts in which                parts showing part number, name, and                    (1) The Contracting officer may retain
                                                  the VA designated agency office does                      quantity required.                                    funds—
                                                  not have electronic invoicing capability                                                                          (i) Where performance under the contract
                                                  as described above.                                       (End of clause)                                       has been determined to be deficient or the
                                                                                                            § 852.211–71      [Removed and reserved].             Contractor has performed in an
                                                  § 832.7001–1       Data transmission.                                                                           unsatisfactory manner in the past; or
                                                                                                            ■ 29. Section 852.211–71 is removed                     (ii) As the contract nears completion, to
                                                    The contractor shall submit electronic                  and reserved.
                                                  payment requests through—                                                                                       ensure that deficiencies will be corrected and
                                                                                                            ■ 30. Section 852.211–72 is revised to                that completion is timely.
                                                    (a) VA’s Electronic Invoice                             read as follows:                                        (2) Examples of deficient performance
                                                  Presentment and Payment System at the                                                                           justifying a retention of funds include, but
                                                  current website address provided in the                   § 852.211–72      Technical Industry                  are not restricted to, the following—
                                                  contract; or                                              Standards.                                              (i) Unsatisfactory progress as determined
                                                    (b) A system that conforms to the X12                     As prescribed in 811.204–70, insert                 by the Contracting Officer;
                                                  electronic data interchange (EDI)                         the following clause:                                   (ii) Failure to meet schedule in Schedule
                                                                                                                                                                  of Work Progress;
                                                  formats established by the Accredited                     TECHNICAL INDUSTRY STANDARDS                            (iii) Failure to present submittals in a
                                                  Standards Center (ASC) chartered by the                   (DATE)                                                timely manner; or
                                                  American National Standards Institute                        (a) The contractor shall conform to the              (iv) Failure to comply in good faith with
                                                  (ANSI).                                                   standards established by: (Contracting                approved subcontracting plans, certifications,
                                                                                                            Officer: Insert name of organization                  or contract requirements.
                                                  § 832.7001–2       Contract clause.                       establishing the requirement, reference title,          (3) Any level of retention shall not exceed
                                                    The Contracting Officer shall insert                    cite and date, e.g., United States Department         10 percent either where there is determined
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  the clause at 852.232–72, Electronic                      of Agriculture (USDA), Institutional Meat             to be unsatisfactory performance, or when
                                                  submission of payment requests, in                        Purchase Specifications (IMPS), Series 100,           the retainage is to ensure satisfactory
                                                  solicitations and contracts exceeding the                 Beef products, Jan 2010) as to (Contracting           completion. Retained amounts shall be paid
                                                                                                            Officer: Insert item and CLIN, e.g. CLIN 0005         promptly upon completion of all contract
                                                  micro-purchase threshold, except those                    Ground Beef).                                         requirements, but nothing contained in this
                                                  for which the Contracting Officer has                        (b) The contractor shall submit proof of           subparagraph shall be construed as limiting
                                                  directed otherwise under 832.7001, and                    conformance to the standard. This proof may           the Contracting Officer’s right to withhold
                                                  those paid with a Governmentwide                          be a label or seal affixed to the equipment or        funds under other provisions of the contract
                                                  commercial purchase card.                                 supplies, warranting that the item(s) have            or in accordance with the general law and



                                             VerDate Sep<11>2014     18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00067   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1


                                                                                   Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules                                                                                            12931

                                                  regulations regarding the administration of                                events as are necessary to cover all                                          (5) The cost schedule shall include
                                                  Government contracts.                                                      component parts of the contract work.                                      separate cost information for the systems
                                                    (b) The Contractor shall submit a schedule                                 (2) Costs as shown on this schedule must                                 listed in the table in this subparagraph (b)(5).
                                                  of cost to the Contracting Officer for approval                            be true costs and the resident engineer may                                The percentages listed below are proportions
                                                  within 30 calendar days after date of receipt                              require the Contractor to submit the original                              of the cost listed in the Contractor’s cost
                                                  of notice to proceed. Such schedule will be                                estimate sheets or other information to
                                                  signed and submitted in triplicate. The                                    substantiate the detailed makeup of the                                    schedule and identify, for payment purposes,
                                                  approved cost schedule will be one of the                                  schedule.                                                                  the value of the work to adjust, correct and
                                                  bases for determining progress payments to                                   (3) The sums of the sub-activities/events,                               test systems after the material has been
                                                  the Contractor for work completed. This                                    as applied to each work activity/event, shall                              installed. Payment of the listed percentages
                                                  schedule shall show cost by the work                                       equal the total cost of such work activity/                                will be made only after the Contractor has
                                                  activity/event for each building or unit of the                            event. The total cost of all work activities/                              demonstrated that each of the systems is
                                                  contract, as instructed by the resident                                    events shall equal the contract price.                                     substantially complete and operates as
                                                  engineer.                                                                    (4) Insurance and similar items shall be                                 required by the contract.
                                                    (1) The work activities/events shall be                                  prorated and included in the cost of each
                                                  subdivided into as many sub-activities/                                    branch of the work.

                                                                                                           VALUE OF ADJUSTING, CORRECTING, AND TESTING SYSTEM
                                                                                                                                              System                                                                                                     Percent

                                                  Pneumatic tube system .......................................................................................................................................................................                    10
                                                  Incinerators (medical waste and trash) ...............................................................................................................................................                            5
                                                  Sewage treatment plant equipment .....................................................................................................................................................                            5
                                                  Water treatment plant equipment ........................................................................................................................................................                          5
                                                  Washers (dish, cage, glass, etc.) ........................................................................................................................................................                        5
                                                  Sterilizing equipment ...........................................................................................................................................................................                 5
                                                  Water distilling equipment ...................................................................................................................................................................                    5
                                                  Prefab temperature rooms (cold, constant temperature) ....................................................................................................................                                        5
                                                  Entire air-conditioning system (Specified under 600 Sections) ..........................................................................................................                                          5
                                                  Entire boiler plant system (Specified under 700 Sections) .................................................................................................................                                       5
                                                  General supply conveyors ...................................................................................................................................................................                     10
                                                  Food service conveyors .......................................................................................................................................................................                   10
                                                  Pneumatic soiled linen and trash system ............................................................................................................................................                             10
                                                  Elevators and dumbwaiters .................................................................................................................................................................                      10
                                                  Materials transport system ..................................................................................................................................................................                    10
                                                  Engine-generator system .....................................................................................................................................................................                     5
                                                  Primary switchgear ..............................................................................................................................................................................                 5
                                                  Secondary switchgear .........................................................................................................................................................................                    5
                                                  Fire alarm system ................................................................................................................................................................................                5
                                                  Nurse call system ................................................................................................................................................................................                5
                                                  Intercom system ..................................................................................................................................................................................                5
                                                  Radio system .......................................................................................................................................................................................              5
                                                  TV (entertainment) system ..................................................................................................................................................................                      5



                                                    (c) In addition to this cost schedule, the                                 (e) The Government reserves the right to                                 notice to proceed, a guarantee period
                                                  Contractor shall submit such unit costs as                                 withhold payment until samples, shop                                       performance program that shall include an
                                                  may be specifically requested. The unit costs                              drawings, engineer’s certificates, additional                              itemized accounting of the number of work-
                                                  shall be those used by the Contractor in                                   bonds, payrolls, weekly statements of                                      hours required to perform the guarantee
                                                  preparing its bid and will not be binding as                               compliance, proof of title, nondiscrimination
                                                                                                                                                                                                        period service on each piece of equipment.
                                                  pertaining to any contract changes.                                        compliance reports, or any other
                                                                                                                             requirements of this contract, have been                                   The Contractor shall also submit the
                                                    (d) The Contracting Officer will consider                                                                                                           established salary costs, including employee
                                                  for monthly progress payments material and/                                submitted to the satisfaction of the
                                                                                                                             Contracting officer.                                                       fringe benefits, and what the contractor
                                                  or equipment procured by the Contractor and
                                                                                                                               (f) The Contracting Officer will notify the                              reasonably expects to pay over the guarantee
                                                  stored on the construction site, as space is
                                                                                                                             Contractor in writing within 10 calendar-                                  period, all of which will be subject to the
                                                  available, or at a local approved location off
                                                                                                                             days of exercising retainage against any                                   Contracting officer’s approval.
                                                  the site, under such terms and conditions as
                                                                                                                             payment in accordance with FAR clause                                         (ii) The cost of the guarantee period service
                                                  the Contracting Officer approves, including                                52.232–5(e). The notice shall disclose the
                                                  but not limited to the following—                                                                                                                     shall be prorated on an annual basis and paid
                                                                                                                             amount of the retainage in value and percent
                                                    (1) The materials or equipment are in                                                                                                               in equal monthly payments by VA during the
                                                                                                                             retained from the payment, and provide
                                                  accordance with the contract requirements                                  explanation for the retainage.                                             period of guarantee. In the event the installer
                                                  and/or approved samples and shop drawings;                                                                                                            does not perform satisfactorily during this
                                                    (2) The materials and/or equipment are                                   (End of clause)                                                            period, all payments may be withheld and
                                                  approved by the resident engineer;                                           Alternate I (DATE). If the specifications                                the Contracting Officer shall inform the
                                                    (3) The materials and/or equipment are                                   include guarantee period services, the                                     contractor of the unsatisfactory performance,
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  stored separately and are readily available for                            Contracting officer shall include the                                      allowing the contractor 10 days to correct
                                                  inspection and inventory by the resident                                   following paragraphs as additions to                                       deficiencies and comply with the contract.
                                                  engineer;                                                                  paragraph (b) of the basic clause:                                         The guarantee period service is subject to
                                                    (4) The materials and/or equipment are                                     (6)(i) The Contractor shall at the time of                               those provisions as set forth in the Payments
                                                  protected against weather, theft and other                                 contract award furnish the total cost of the
                                                  hazards and are not subjected to                                                                                                                      and Default clauses.
                                                                                                                             guarantee period services in accordance with
                                                  deterioration; and                                                         specification section(s) covering guarantee
                                                    (5) The Contractor obtains the concurrence
                                                                                                                                                                                                        ■ 33. Add section 852.232–71 to read as
                                                                                                                             period services. The Contractor shall submit,
                                                  of its surety for off-site storage.                                        within 15 calendar days of receipt of the                                  follows:



                                             VerDate Sep<11>2014         18:14 Mar 23, 2018         Jkt 244001       PO 00000       Frm 00068       Fmt 4702       Sfmt 4702       E:\FR\FM\26MRP1.SGM              26MRP1


                                                  12932                            Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules

                                                  § 852.232–71 Payments under fixed-price                                      (i) Unsatisfactory progress as determined                                be one of the bases for determining progress
                                                  construction contracts (including NAS–                                     by the Contracting Officer;                                                payments to the Contractor for work
                                                  CPM).                                                                        (ii) Failure to meet schedule in Schedule                                completed.
                                                                                                                             of Work Progress;                                                             (1) Costs as shown on this schedule must
                                                    As prescribed in 832.111–70, insert                                        (iii) Failure to present submittals in a                                 be true costs and the resident engineer may
                                                  the following clause in contracts that                                     timely manner; or                                                          require the contractor to submit its original
                                                  contain a section entitled ‘‘Network                                         (iv) Failure to comply in good faith with                                estimate sheets or other information to
                                                  Analysis System—Critical Path Method                                       approved subcontracting plans, certifications,                             substantiate the detailed makeup of the cost
                                                  (NAS–CPM).’’                                                               or contract requirements.                                                  schedule.
                                                                                                                               (3) Any level of retention shall not exceed                                 (2) The total costs of all work activities/
                                                  Payments Under Fixed-Price Construction                                    10 percent either where there is determined                                events shall equal the contract price.
                                                  Contracts (Including NAS–CPM) (Date)                                       to be unsatisfactory performance, or when
                                                                                                                                                                                                           (3) Insurance and similar items shall be
                                                    The clause FAR 52.232–5, Payments under                                  the retainage is to ensure satisfactory
                                                                                                                                                                                                        prorated and included in each work activity/
                                                  Fixed-Price Construction Contracts, is                                     completion. Retained amounts shall be paid
                                                                                                                             promptly upon completion of all contract                                   event cost of the critical path method (CPM).
                                                  implemented as follows:                                                                                                                                  (4) The CPM shall include a separate cost
                                                                                                                             requirements, but nothing contained in this
                                                    (a) Retainage.                                                                                                                                      loaded activity for adjusting and testing of
                                                                                                                             subparagraph shall be construed as limiting
                                                    (1) The Contracting Officer may retain                                   the Contracting Officer’s right to withhold                                the systems listed in the table in paragraph
                                                  funds—                                                                     funds under other provisions of the contract                               (b)(5) of this section. The percentages listed
                                                    (i) Where performance under the contract                                 or in accordance with the general law and                                  below will be used to determine the cost of
                                                  has been determined to be deficient or the                                 regulations regarding the administration of                                adjust and test work activities/events and
                                                  Contractor has performed in an                                             Government contracts.                                                      identify, for payment purposes, the value of
                                                  unsatisfactory manner in the past; or                                        (b) The Contractor shall submit a schedule                               the work to adjust, correct and test systems
                                                    (ii) As the contract nears completion, to                                of costs in accordance with the requirements                               after the material has been installed.
                                                  ensure that deficiencies will be corrected and                             of section ‘‘Network Analysis System —                                        (5) Payment for adjust and test activities
                                                  that completion is timely.                                                 Critical Path Method (NAS–CPM)’’ to the                                    will be made only after the Contractor has
                                                    (2) Examples of deficient performance                                    Contracting Officer for approval within 90                                 demonstrated that each of the systems is
                                                  justifying a retention of funds include, but                               calendar days after date of receipt of notice                              substantially complete and operates as
                                                  are not restricted to, the following—                                      to proceed. The approved cost schedule will                                required by the contract.

                                                                                                           VALUE OF ADJUSTING, CORRECTING, AND TESTING SYSTEM
                                                                                                                                              System                                                                                                     Percent

                                                  Pneumatic tube system .......................................................................................................................................................................                    10
                                                  Incinerators (medical waste and trash) ...............................................................................................................................................                            5
                                                  Sewage treatment plant equipment .....................................................................................................................................................                            5
                                                  Water treatment plant equipment ........................................................................................................................................................                          5
                                                  Washers (dish, cage, glass, etc.) ........................................................................................................................................................                        5
                                                  Sterilizing equipment ...........................................................................................................................................................................                 5
                                                  Water distilling equipment ...................................................................................................................................................................                    5
                                                  Prefab temperature rooms (cold, constant temperature) ....................................................................................................................                                        5
                                                  Entire air-conditioning system (Specified under 600 Sections) ..........................................................................................................                                          5
                                                  Entire boiler plant system (Specified under 700 Sections) .................................................................................................................                                       5
                                                  General supply conveyors ...................................................................................................................................................................                     10
                                                  Food service conveyors .......................................................................................................................................................................                   10
                                                  Pneumatic soiled linen and trash system ............................................................................................................................................                             10
                                                  Elevators and dumbwaiters .................................................................................................................................................................                      10
                                                  Materials transport system ..................................................................................................................................................................                    10
                                                  Engine-generator system .....................................................................................................................................................................                     5
                                                  Primary switchgear ..............................................................................................................................................................................                 5
                                                  Secondary switchgear .........................................................................................................................................................................                    5
                                                  Fire alarm system ................................................................................................................................................................................                5
                                                  Nurse call system ................................................................................................................................................................................                5
                                                  Intercom system ..................................................................................................................................................................................                5
                                                  Radio system .......................................................................................................................................................................................              5
                                                  TV (entertainment) system ..................................................................................................................................................................                      5



                                                    (c) In addition to this cost schedule, the                                 (2) The materials and/or equipment are                                   compliance reports, or any other
                                                  Contractor shall submit such unit costs as                                 approved by the resident engineer;                                         requirements of this contract, have been
                                                  may be specifically requested. The unit costs                                (3) The materials and/or equipment are                                   submitted to the satisfaction of the
                                                  shall be those used by the Contractor in                                   stored separately and are readily available for                            Contracting Officer.
                                                  preparing its bid and will not be binding as                               inspection and inventory by the resident                                     (f) The Contracting Officer will notify the
                                                  pertaining to any contract changes.                                        engineer;                                                                  Contractor in writing within 10 calendar-
                                                    (d) The Contracting Officer will consider                                  (4) The materials and/or equipment are                                   days of exercising retainage against any
                                                  for monthly progress payments material and/                                protected against weather, theft and other                                 payment in accordance with FAR clause
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  or equipment procured by the Contractor and                                hazards and are not subjected to                                           52.232–5(e). The notice shall disclose the
                                                  stored on the construction site, as space is                               deterioration; and                                                         amount of the retainage in value and percent
                                                  available, or at a local approved location off                               (5) The contractor obtains the concurrence                               retained from the payment, and provide
                                                  the site, under such terms and conditions as                               of its surety for off-site storage.                                        explanation for the retainage.
                                                  the Contracting Officer approves, including                                  (e) The Government reserves the right to
                                                  but not limited to the following—                                          withhold payment until samples, shop                                       (End of clause)
                                                    (1) The materials or equipment are in                                    drawings, engineer’s certificates, additional                                Alternate I (DATE). If the specifications
                                                  accordance with the contract requirements                                  bonds, payrolls, weekly statements of                                      include guarantee period services, the
                                                  and/or approved samples and shop drawings;                                 compliance, proof of title, nondiscrimination                              Contracting officer shall include the



                                             VerDate Sep<11>2014         18:14 Mar 23, 2018         Jkt 244001       PO 00000       Frm 00069       Fmt 4702       Sfmt 4702       E:\FR\FM\26MRP1.SGM              26MRP1


                                                                          Federal Register / Vol. 83, No. 58 / Monday, March 26, 2018 / Proposed Rules                                            12933

                                                  following paragraphs as additions to                    Government-wide commercial purchase card              DEPARTMENT OF TRANSPORTATION
                                                  paragraph (b) of the basic clause:                      are considered to be an electronic transaction
                                                    (6)(i) The Contractor shall show on the               for purposes of this rule, and therefore no           Federal Motor Carrier Safety
                                                  critical path method (CPM) the total cost of            additional electronic invoice submission is           Administration
                                                  the guarantee period services in accordance             required.
                                                  with the guarantee period service section(s)              (c) Data transmission. A contractor must
                                                  of the specifications. This cost shall be priced
                                                                                                                                                                49 CFR Chapter III, Subchapter B
                                                                                                          ensure that the data transmission method and
                                                  out when submitting the CPM cost loaded                                                                       [Docket No. FMCSA–2018–0037]
                                                  network. The cost submitted shall be subject            format are through one of the following:
                                                  to the approval of the Contracting Officer.               (1) VA’s Electronic Invoice Presentment             Request for Comments Concerning
                                                  The activity on the CPM shall have money                and Payment System at the current website             Federal Motor Carrier Safety
                                                  only and not activity time.                             address provided in the contract.                     Regulations (FMCSRs) Which May Be
                                                    (ii) The Contractor shall submit with the               (2) Any system that conforms to the X12             a Barrier to the Safe Testing and
                                                  CPM a guarantee period performance                      electronic data interchange (EDI) formats             Deployment of Automated Driving
                                                  program which shall include an itemized                 established by the Accredited Standards
                                                  accounting of the number of work-hours                                                                        Systems-Equipped Commercial Motor
                                                                                                          Center (ASC) and chartered by the American            Vehicles on Public Roads
                                                  required to perform the guarantee period                National Standards Institute (ANSI).
                                                  service on each piece of equipment. The                   (d) Invoice requirements. Invoices shall            AGENCY:  Federal Motor Carrier Safety
                                                  Contractor shall also submit the established
                                                                                                          comply with FAR 32.905.                               Administration (FMCSA), DOT.
                                                  salary costs, including employee fringe
                                                  benefits, and what the contractor reasonably              (e) Exceptions. If, based on one of the             ACTION: Request for comments.
                                                  expects to pay over the guarantee period, all           circumstances below, the Contracting Officer
                                                  of which will be subject to the Contracting             directs that payment requests be made by              SUMMARY:    FMCSA requests public
                                                  Officer’s approval.                                     mail, the contractor shall submit payment             comments on existing Federal Motor
                                                    (iii) The cost of the guarantee period                requests by mail through the United States            Carrier Safety Regulations (FMCSRs)
                                                  service shall be prorated on an annual basis            Postal Service to the designated agency               that may need to be updated, modified,
                                                  and paid in equal monthly payments by VA                office. Submission of payment requests by             or eliminated to facilitate the safe
                                                  during the period of guarantee. In the event            mail may be required for—                             introduction of automated driving
                                                  the installer does not perform satisfactorily             (1) Awards made to foreign vendors for              systems (ADS) equipped commercial
                                                  during this period, all payments may be                 work performed outside the United States;             motor vehicles (CMVs) onto our
                                                  withheld and the Contracting Officer shall                                                                    Nation’s roadways. To assist in this
                                                                                                            (2) Classified contracts or purchases when
                                                  inform the contractor of the unsatisfactory                                                                   undertaking, FMCSA commissioned the
                                                  performance, allowing the Contractor 10 days            electronic submission and processing of
                                                  to correct and comply with the contract. The            payment requests could compromise the                 U.S. Department of Transportation’s
                                                  guarantee period service is subject to those            safeguarding of classified or privacy                 John A. Volpe National Transportation
                                                  provisions as set forth in the Payments and             information;                                          Systems Center (Volpe) to conduct a
                                                  Default clauses.                                          (3) Contracts awarded by Contracting                preliminary review of the FMCSRs to
                                                                                                          Officers in the conduct of emergency                  identify regulations that may relate to
                                                  ■ 34. Section 852.232–72 is revised to
                                                                                                          operations, such as responses to national             the development and safe introduction
                                                  read as follows:
                                                                                                          emergencies;                                          of ADS. The Agency requests comments
                                                  § 852.232–72 Electronic submission of                     (4) Solicitations or contracts in which the         on this report, including whether any of
                                                  payment requests.                                       designated agency office is a VA entity other         FMCSA’s current safety regulations may
                                                    As prescribed in 832.7001–2, insert                   than the VA Financial Services Center in              hinder the testing and safe integration of
                                                  the following clause:                                   Austin, Texas; or                                     ADS-equipped CMVs. Further, FMCSA
                                                                                                            (5) Solicitations or contracts in which the         requests comment on certain specific
                                                  Electronic Submission of Payment Requests               VA designated agency office does not have             regulatory requirements that are likely
                                                  (Date)                                                  electronic invoicing capability as described          to be affected by an increased
                                                    (a) Definitions. As used in this clause—              above.                                                integration of ADS-equipped CMVs.
                                                    (1) Contract financing payment has the                                                                      However, the Agency is not seeking
                                                  meaning given in FAR 32.001.                            (End of clause)
                                                    (2) Designated agency office means the
                                                                                                                                                                comments on its financial responsibility
                                                  office designated by the purchase order,                § 852.236–82      [Removed and reserved].
                                                                                                                                                                requirements because they are not
                                                  agreement, or contract to first receive and                                                                   directly related to CMV technologies
                                                  review invoices. This office can be                     § 852.236–83      [Removed and reserved].             and because future insurance
                                                  contractually designated as the receiving                                                                     requirements will depend in part on the
                                                  entity. This office may be different from the           ■ 35. Remove and reserve sections                     evolution of State tort law with respect
                                                  office issuing the payment.                             852.236–82 and 852.236–83.                            to liability for the operation of ADS-
                                                    (3) Electronic form means an automated                                                                      equipped vehicles. In addition, to
                                                  system transmitting information                         PART 870—SPECIAL PROCUREMENT
                                                                                                                                                                support FMCSA’s effort to understand
                                                  electronically according to the accepted                CONTROLS
                                                  electronic data transmission methods and
                                                                                                                                                                future impacts on the FMCSR’s, FMCSA
                                                  formats identified in paragraph (c) of this             ■  36. The authority citation for part 870            requests information, including from
                                                  clause. Facsimile, email, and scanned                   is revised to read as follows:                        companies engaged in the design,
                                                  documents are not acceptable electronic                                                                       development, testing, and integration of
                                                  forms for submission of payment requests.                 Authority: 40 U.S.C. 121(c); 41 U.S.C.              ADS-equipped CMVs into the fleet.
                                                    (4) Invoice payment has the meaning given             1702; and 48 CFR 1.301–1.304.                         Specifically, the Agency requests
sradovich on DSK3GMQ082PROD with PROPOSALS




                                                  in FAR 32.001.                                                                                                information about: The scenarios and
                                                    (5) Payment request means any request for             § 870.112    [Removed]
                                                                                                                                                                environments where entities expect that
                                                  contract financing payment or invoice                                                                         ADS will soon be tested and integrated
                                                  payment submitted by the contractor under               § 870.113    [Removed]
                                                  this contract.
                                                                                                                                                                into CMVs operating on public roads or
                                                                                                          ■ 37. Remove sections 870. 112 and                    in interstate commerce; the operational
                                                    (b) Electronic payment requests. Except as            870.113.
                                                  provided in paragraph (e) of this clause, the                                                                 design domains (ODD) in which these
                                                  contractor shall submit payment requests in             [FR Doc. 2018–04002 Filed 3–23–18; 8:45 am]           systems are being operated or would be
                                                  electronic form. Purchases paid with a                  BILLING CODE 8320–01–P                                tested and eventually deployed; and,


                                             VerDate Sep<11>2014   18:14 Mar 23, 2018   Jkt 244001   PO 00000   Frm 00070   Fmt 4702   Sfmt 4702   E:\FR\FM\26MRP1.SGM   26MRP1



Document Created: 2018-03-24 00:59:56
Document Modified: 2018-03-24 00:59:56
CategoryRegulatory Information
CollectionFederal Register
sudoc ClassAE 2.7:
GS 4.107:
AE 2.106:
PublisherOffice of the Federal Register, National Archives and Records Administration
SectionProposed Rules
ActionProposed rule.
DatesComments must be received on or before May 25, 2018 to be considered in the formulation of the final rule.
ContactMr. Ricky Clark, Senior Procurement Analyst, Procurement Policy and Warrant Management Services, 003A2A, 425 I Street NW, Washington DC 20001, (202) 697-3565. (This is not a toll-free telephone number.)
FR Citation83 FR 12922 
RIN Number2900-AP81
CFR Citation48 CFR 801
48 CFR 811
48 CFR 832
48 CFR 852
48 CFR 870
CFR AssociatedAdministrative Practice and Procedure; Government Procurement; Reporting and Recordkeeping Requirements; Asbestos; Frozen Foods and Telecommunications

2025 Federal Register | Disclaimer | Privacy Policy
USC | CFR | eCFR